Loading...
HomeMy WebLinkAboutR-2002-062 r` RESOLUTION NO. 2002-062 A RESOLUTION OF THE CITY OF DANIA BEACH, FLORIDA AWARDING THE BID FOR CONSTRUCTION OF FLOATING DOCKS AT WHISKEY CREEK TO DURABLE INSTALLATIONS, INC., IN THE AMOUNT OF FORTY NINE THOUSAND NINE HUNDRED SEVENTY FIVE DOLLARS ($49,975.00) AUTHORIZING THE PROPER CITY OFFICIALS TO EXECUTE AN AGREEMENT WITH DURABLE INSTALLATIONS, INC. AND THE CITY OF DANIA BEACH; PROVIDING FOR CONFLICTS; FURTHER, PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, the Charter of the City of Dania Beach, Part III, Article 3, Section 4, Subsection (J), authorizes that contracts for the purchase of supplies, services, equipment and materials for the city government in excess of fifteen thousand dollars ($15,000.00) shall not be entered into or let except by authorization and approval of the city commission, after advertisement for bids in a newspaper published in Broward County, Florida, with such publication to be published weekly for two (2) consecutive weeks with the first publication to be not less than fifteen (15) days prior the reception of bids; and WHEREAS, in order to reduce maintenance costs and provide better level of service, the City of Dania Beach has been working on the Floating Docks Project; and WHEREAS, bids and specifications for the Floating Docks Project were advertised and received on April 22, 2002; and WHEREAS, the City Manager has determined, after review of the bids received, that such project can be made at the least cost to the City by awarding the bid to Durable Installations, Inc., in the amount of Forty Nine Thousand Nine Hundred and Seventy Five Dollars ($49,975.00) for the construction and installation of three (3) "T"-head floating docks, one (1) rectangular floating dock, one handicap ramp and piles at the existing docks located at the west side of the municipal parking lot at North Beach Road. 1 RESOLUTION NO. 2002-062 r' NOW, THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION OF THE CITY OF DANIA BEACH, FLORIDA: Section 1. That the contract and bid documents received from Durable Installations, Inc., in the amount of Forty Nine Thousand Nine Hundred and Seventy Five Dollars ($49,975.00) in substantial form as Exhibit "A", attached, are approved and the appropriate city officials are authorized to execute same. Section 2. That the City Manager is authorized to pay Durable Installations, Inc., an amount not to exceed $49,975.00 from the General Fund Budget, with the understanding that the City would be reimbursed from grant funds provided through the Broward Boating Improvement Grant Program. Section 3. That the City Manager and City Attorney are authorized to make minor revisions to such Agreement as are deemed necessary and proper for the best interests of • the City. Such Agreement and award of the bid shall not be deemed accepted by the City unless and until the City has completed its execution of the Agreement. Section 4. That all resolutions or parts of resolutions in conflict with this resolution are repealed to the extent of such conflict. Section 5. That this resolution shall be in force and take effect immediately upon its passage and adoption. PASSED and ADOPTED this 14t of MAY, 2002. ROB RT H. CHUNN, JR. MAY .R — COMMISSIONER 2 RESOLUTION NO. 2002-062 1 ATTEST: ROLL CALL: COMMISSIONER BERTINO - YES AAX COMMISSIONER MCELYEA - YES CHA LENE JO SON COMMISSIONER MIKES - YES CITY CLERK VICE-MAYOR FLURY - YES MAYOR CHUNN - YES APPROVED AS TO FOIAM AND CORRECTNESS: BY: THOMA8 J. ANSBRO CITY ATTORNEY • 3 RESOLUTION NO. 2002-062 561 2241 4591 Jun 04 02 01 : 54p DECK COVERS 5G1 241 4591 p. 1 DURABLE INSTALLATIONS, Inc. Established 1977 DISTRIBUTORS OF DURABLE DECKING GENERAL,CONTRACTING 518 NW 77th Street, Boca Raton, Florida 33487 CGCA 10072 (561) 241-4667 office,(561)241-4591 fax June 4, 2002 City of Dania Beach 100 West Dania Beach Boulevard Dania Beach, Florida 33004 ATTN: Ms. Charlene Johnson, City Clerk Dear Ms. Johnson, We hereby respectfully are withdrawing our Proposal for the Whiskey Creek Floating Dock Project. We can not meet the terms the City of Dania has requested in their agreement. We either want the city to drop the request for a performance Bond, or give us a 50% deposit for the. work. We will not agree to both a bond an no deposit. Should you reconsider our request, we will be happy to complete the project. Sinc ly, hl pl i, President ble nstallations, Inc. r "eta. FLORIDA May 24, 2002 Mr. Flip Kaplan President Durable Installations Inc. 518 NW 77th Street Boca Raton, FL. 33487 RE: AGREEMENT BETWEEN THE CITY OF DANIA BEACH AND DURABLE INSTALLATIONS INC. FOR CONSTRUCTION OF FLOATING DOCKS AT WHISKEY CREEK Dear Mr. Kaplan.- On May 14, 2002, the Dania Beach City Commission adopted Resolution • No. 2002-062 approving the above agreement. We are enclosing a copy of the resolution and two signed originals of the agreement. Once you have executed the signature page on these documents, please include the date on page one of each agreement. Please retain one original and return the other one to me. In regards to Article 8 of the agreement, please contact Mary McDonald, Human Resources/Risk Management Director, at (954) 924-3630. All other aspects of the agreement should be forwarded to Ken Koch, Building Official, at 954-924-3650. Sincerely, r kene John on City Clerk CJ/mn Enclosures • "Broward's First City" 100 West Dania Beach Boulevard Dania Beach, Florida 33004 Phone: (954) 921-8700 www.ci.dania-beach.fl.us AGREEMENT v THIS IS AN AGREEMENT ("Agreement"), datedWbetween: THE CITY OF DANIA BEACH ("City"), a Florida municiption, with a business location at 100 WEST DANIA BEACH BOULEVARD, DANIA BEACH, FLORIDA 33004, and DURABLE INSTALLATIONS, INC. ("Contractor"), a Florida Corporation, with its principal place of business located at 518 NW 77 Street, Boca Raton, FL 33487. In consideration of the mutual terms, conditions, promises, covenants and payments set forth in this Agreement, the sufficiency and receipt of which are acknowledged, City and Contractor agree as follows: ARTICLE 1 PREAMBLE In order to establish the background, context and frame of reference for this Agreement, and to generally express the objectives and intentions of the parties, the following statements, representations and explanations are the predicates for the undertakings and commitments included within the provisions which follow, and may be relied upon by the parties as essential elements of the mutual considerations upon which this Agreement is based. 1.1 The Contractor, for the consideration fully set out below, shall furnish all the materials, equipment and labor to perform all work necessary to complete the Project, all in full and complete accordance with Plans and Specifications by EDC Corp. (dated 11/02/01, revised 03/05/02), Exhibit "A" and City's Invitation to Bid, which are both attached and made parts of this Agreement. The "Project" consists of materials, equipment and labor necessary to complete the installation of 3 "T" Head Floating Docks, 1 Rectangular Floating Dock with Platform, Handicap Ramp and Piles at Whiskey Creek, New River Sound, located at the west side of the Municipal Parking Lot, North Ocean Drive, Dania Beach FL, as such items are more particularly described in the Specifications which are a part of Contractor's executed Bid Proposal, which proposal is incorporated into and made a part of this Agreement as Exhibit"A", attached. 1.2 The City advertised its notice to bidders of the City's desire to have the Project completed,pursuant to the bid entitled: • 1 BID PROPOSAL FOR FLOATING DOCK PROJECT WHISKEY CREEK NEW RIVER SOUND DANIA BEACH, FLORIDA 1.3 On May 14, 2002, the City awarded the bid to Contractor and authorized the proper City officials to enter into this Agreement with Contractor to complete the Project. ARTICLE 2 SERVICES AND RESPONSIBILITIES 2.1 Contractor agrees to do everything required by this Agreement and to comply with any and all other provisions in the documents and items incorporated by reference into this Agreement. Contractor also agrees to perform all clean-up and bear the expense of any off-site disposal, which is or may be necessitated by its work on and around the Project site. 2.2 Contractor agrees that all work performed under this Agreement shall be done in a professional manner and that Contractor's efforts will produce a quality result. 2.3 Contractor represents to City, with full knowledge that City is relying upon these representations when entering into this Agreement with Contractor, that Contractor has the expertise, experience and work force sufficient to timely perform the services to be provided by Contractor pursuant to the terms of this Agreement. 2.4 Contractor represents to City that Contractor is properly licensed by all applicable federal, state and local agencies to provide the services specified under this Agreement. If any of the Contractor's licenses are revoked, suspended or terminated for any reason by any governmental agency, Contractor shall notify the City immediately. 2.5 Contractor agrees to conduct all work and services under this Agreement in accordance with all applicable federal, state and local laws and regulations. Contractor will identify all governmental authorities and agencies having jurisdiction to approve work involved in the Project and Contractor agrees to obtain all permits and approvals from any and all such governmental authorities which have jurisdiction. If permitted by the permitting agency, and if City can realize a cost savings by such action, City may authorize the Contractor to seek required permits on behalf of and in the name of City as its Contractor; provided, however, that Contractor agrees to fully indemnify and hold harmless the City in all respects as a result of the obtaining of any and all such permits and approvals. Without limiting the foregoing, City agrees to reimburse Contractor, upon City's receipt of adequate proof that Contractor has paid same, the amounts of all permit fees incurred by Contractor in connection with the . applications, processing and securing of approvals or permits which are required to be obtained from all governmental authorities which have jurisdiction over any and all 2 aspects of this work, except City permits and fees which shall be waived and except for so much of any fees as to which the City is required to remit to other governmental agencies. 2.6 City's Building Official, or his designated representative, will be the person through whom Contractor must communicate all information pertaining to the Project. 2.7 Contractor shall guarantee the entire Project against poor workmanship and faulty materials for a period of one (1) year after final payment and shall immediately correct any defects which may appear during this period upon written notification by the City's Building Official or his designated representative. Contractor waives any and all rights to claim any statute of limitations defense as to any condition that may arise under this guarantee. ARTICLE 3 TERMS AND CONDITIONS 3.1 Contractor shall begin to perform the Project work commencing no later than thirty (30) days from the date first above written and shall notify City in writing of the date work will commence (the "Commencement Date"). Contractor shall complete the Project work no later than sixty (60) days after the Commencement Date (the "Completion Date"). Contractor shall notify City in writing of the Completion Date within 10 days of the Commencement Date. 3.2 This Agreement may be terminated by City if Contractor fails to perform the work to City's sole and reasonable approval, after City sends written notice of any deficiency to Contractor and Contractor does not cure such deficiency within seven (7) days from the date of such notice. In such event, the Contractor shall be paid compensation for improvements made toward completion of the Project, if such improvements meet City's sole and reasonable approval, which approval will not be unreasonably withheld. In the event that the Contractor abandons the work specified in this Agreement or causes it to be terminated, Contractor shall indemnify the City against any loss pertaining to its abandonment up to a maximum of the amount to be paid under this Agreement. All finished or unfinished materials, documents and reports prepared by Contractor shall become the property of City and shall be delivered by Contractor to City before payment, if any, is made to Contractor by City. ARTICLE 4 COMPENSATION AND METHOD OF PAYMENT 4.1 City agrees to compensate Contractor, as follows: one-third upon complete execution of this Agreement by both parties (i.e., $16,658.33) and the balance (i.e., $33,316.67) no later than twenty (20) business days after the City Building Official or his designated representative approves all of Contractor's completed Project work pursuant to the provisions of this Agreement. TOTAL AGREEMENT AMOUNT is ® $49,975.00. 3 Project completion shall be evidenced by a writing to that effect, issued by the City Building Official and given to the City Clerk. The total compensation above may not be exceeded without a written amendment to this Agreement executed by the authorized agents of both of the parties. 4.2 Payment will be made to Contractor at: Philip Kaplan, President Durable Installations, Inc. 518 NW 77 Street Boca Raton, Fl 33487 (561)-241-4667 Fax (561)-241-4591 4.3 The making and acceptance of the work shall constitute a waiver of all claims by the City except for any or all claims arising from the guarantee set forth above, unsettled liens, lawsuits, deficiencies or faulty work appearing within one (1) year after final payment, or from any variations from the requirements of the Specifications for the Project. The acceptance of payment shall constitute a waiver of all claims against City by the Contractor. 4.4 Contractor shall, before final payment is made by City, provide City copies of releases of all liens from any and all subcontractors, materials' providers and the like, who or which supplied or furnished any labor, services or materials that were used in the Project. Contractor shall then furnish the City a"No Lien Affidavit". Final payment shall be made upon submission by the Contractor of evidence satisfactory to the City that all payrolls, material bills and other costs incurred by the Contractor in connection with the work, have been paid in full, and after all guarantees and specifications for products and/or materials incorporated into the project that appear in this Agreement and as otherwise set forth in the specifications have been furnished to and found acceptable by the City. ARTICLE 5 CHANGES IN SCOPE OF WORK City or Contractor may request changes that increase, decrease or otherwise modify the Project, as described in this Agreement. These changes may affect the compensation specified above and, if so, they must be described in a written amendment, executed by the authorized agents of both of the parties, prior to any deviation from the terms of this Agreement. In no event will Contractor deviate or permit deviation from the work described in this Agreement or the Specifications without City's advance written consent. ARTICLE 6 PROTECTION OF CITY'S PROPERTY 4 At all times during the performance of this Agreement, the Contractor shall protect the City's property from all damage whatsoever on account of Contractor's performance of work toward completion of the Project described by this Agreement. ARTICLE 7 INDEMNIFICATION 7.1 The Contractor agrees to indemnify and hold harmless the City and its elected and appointed officers, agents, servants and employees, from and against any and all claims, demands or causes of action whatsoever, and the resulting losses, costs, expenses, reasonable attorneys' fees, liabilities, damages, orders,judgments and decrees, sustained by the City and any third party arising out of, or by reason of, or resulting from the Contractor's work toward completion of the Project, Contractor's reckless acts, or negligent acts, or both and any and all errors or omissions of whatsoever kind up to a maximum amount of the Total Agreement Amount. 7.2 The Contractor agrees to release the City from and against any and all liability and responsibility in connection with the Project work. If Contractor exposes City to liability for any reason arising out of the Project work, Contractor's compensation may be withheld until City can determine the extent of City's exposure and City retains the right to offset any amounts related to such matters against Contractor's compensation, if any. City will notify Contractor in writing when it determines Contractor may have exposed City to any liability and City will provide a reasonably ascertainable date by which resolution of the exposure, offset or both will be determined. ARTICLE 8 INSURANCE 8.1 The Contractor shall not commence work under this Agreement until Contractor has obtained all insurance required under section 8.4 of this Article ("Coverage") and such Coverage has been approved by the Risk Manager of the City. The Contractor shall not allow any subcontractor to commence work on any subcontract until the subcontractor, as provided in section 14.3, below, and all Coverage required of any subcontractor, have been approved by City. In addition, Contractor shall be responsible for any policy deductibles and self-insured retentions. 8.2 Contractor shall file Certificates of Insurance with the City, reflecting evidence of the Coverage. They shall be filed with the City Risk Manager within ten (10) days of the date first above written. These Certificates shall contain a provision that Coverage afforded under these policies will not be canceled until at least thirty (30) days prior written notice has been given to the City. Policies for Coverage shall be issued by companies authorized to do business under the laws of the State of Florida and any such companies' financial ratings must be no less than "A" in the latest edition of the "BEST'S KEY RATING GUIDE", published by A.M. Best Guide. 5 8.3 Coverage shall be in force until all work required to be performed under the terms of this Agreement is satisfactorily completed as evidenced by the formal acceptance by the City. In the event insurance certificates provided to City indicate that the insurance shall terminate and lapse during the period of this Agreement, then in that event, the Contractor shall furnish, at least thirty (30) days prior to the expiration of the date of such insurance, a renewed certificate of insurance as proof that equal and like Coverage for the balance of the period of the Agreement and any extension of it is in effect. THE CONTRACTOR SHALL NOT PERFORM OR CONTINUE TO WORK PURSUANT TO THIS AGREEMENT UNLESS ALL COVERAGE REMAINS IN FULL FORCE AND EFFECT, SUCH DELAY BEING SUBJECT TO ANY APPLICABLE PROVISIONS DESCRIBED IN THIS AGREEMENT. 8.4 REQUIRED INSURANCE COVERAGE. 8.4.1 General Liability Insurance includes products, completed operations and blanket contractual liability with bodily injury limits of not less than $1,000,000.00 per occurrence combined single limit for bodily injury and property damage. City shall be named as an "additional named insured" under the general liability policy including product liability. "Additional named insured" clause shall be a rider or endorsement issued by the insurance home office, not by a local agent. 8.4.2 Workers' Compensation insurance shall be maintained by Contractor during the Life of this Agreement to comply with statutory limits for all employees, and in the case any work is sublet, as otherwise addressed in this Agreement, the Contractor shall require any subcontractors similarly to provide Workers' Compensation Insurance for all of the latter's employees unless such employees are covered by the protection afforded by the Contractor. The Contractor and its subcontractors shall maintain during the life of this policy Employers' Liability Insurance. The following limits must be maintained: $500,000.00 with not less than $100,000.00 per occurrence. 8.4.3 Comprehensive Auto Liability insurance with limits not less than $500,000.00 per occurrence for bodily injury and property damage. This coverage shall include owned,hired and non-owned vehicles. The Contractor shall hold the City, its agents and employees, harmless on account of claims for damages to persons, property or premises arising out of the operations to complete the Project. The City reserves the right to require Contractor to provide and pay for any other insurance coverage City deems necessary depending upon the possible exposure to liability. 6 ARTICLE 9 INDEPENDENT CONTRACTOR This Agreement does not create an employee/employer relationship between the parties. Contractor agrees that it is not the City's employee for any purposes, including but not limited to, the application of the Fair Labor Standards Act minimum wages' laws and overtime payments, Federal Insurance Contribution Act, the Social Security Act, the Federal Unemployment Tax Act, the provisions of the Internal Revenue Code, the Florida Workers' Compensation Act, and the Florida unemployment insurance law. The Contractor shall retain sole and absolute discretion and exercise its judgment as to the manner and means of carrying out Contractor's activities and responsibilities toward completion of the Project. Administrative procedures applicable to services rendered under this Agreement shall be those of Contractor, which policies of Contractor shall not conflict with City, H.U.D., or United States policies, rules or regulations relating to the use of Contractor's funds provided for in this Agreement. The Contractor agrees that it is a separate and independent enterprise from the City, that it has full opportunity to find other business, that it has made its own investment in its business, and that it will utilize a high level of skill necessary to perform the work. This Agreement shall not be construed as creating any joint employment relationship between the Contractor and the City and the City will not be liable for any obligation incurred by Contractor, including but not limited to unpaid minimum wages, overtime premiums or both. ARTICLE 10 PUBLIC CONSTRUCTION BOND 10.1 At the time of the execution of this Agreement, Contractor shall furnish a Public Construction Bond equal to the amount of the bid, or an Irrevocable Letter of Credit acceptable to City in the amount of one hundred fifty percent (150%) of the bid from Contractor's lending institution which will be considered Bond Coverage for the City (in either case, the guarantee is referred to in this Article 10 as the "Bond"). If a Public Construction Bond is submitted, it will be in the form prescribed by Florida law (a copy of such Bond is attached to this Agreement, identified as Exhibit "B" and incorporated by this reference). Any authorized Bond shall guarantee to the City the completion and performance of the work covered in the Agreement. The Bond shall at all times be valid and in force to cover the work being performed. The Bond shall be executed by a Surety Company approved by the U.S. Treasury Department, licensed to do business in the State of Florida, and having a registered agent in Broward County (the "Surety") or, if an Irrevocable Letter of Credit is supplied, it must first be reviewed and approved in writing as acceptable to City in all respects, including the identity and location of the issuing bank, by the City's Chief Financial Officer, which approval will not be unreasonably withheld. 7 10.2 The Contractor agrees to keep any such Bond, or a replacement of it, in full force and effect at all times during the course of performance of this Agreement. In addition to the foregoing requirements, such Bond shall contain provisions, whether by attaching endorsements or supplemental agreements, guaranteeing to the City the completion of the work described in this Agreement. Contractor may comply with the requirements of this provision by causing the Bond to specifically name the CITE' OF DANIA BEACH as one of the parties to whom the protection afforded by the Bond is extended or as an alternative, may furnish the City with a separate Bond meeting the same criteria provided above. ARTICLE 11 DEFAULT OF AGREEMENT AND REMEDIES 11.1 Liquidated Damages. It is mutually agreed between the parties that time is of the essence of this Agreement, and in the event the Project is not completed within the time and in the manner specified in this Agreement, it is agreed that from the compensation otherwise to be paid to the Contractor, the City may retain the sum of Two Hundred ($200.00) Dollars per day for each day thereafter, Sundays and holidays included, that the work remains uncompleted and the City is denied full benefit of completion of the Project, which sum City and Contractor agree represents the damages the City will have sustained per day for the failure of the Contractor to complete the Project within the time stipulated. The parties agree that this sum is not a penalty. 11.2 Remedies in Default. In case of any default by Contractor, the City, through City's Building Official or his designated representative, shall notify the Contractor, in writing, of such default and direct Contractor to comply with all provisions of the Agreement. A copy of such written notice shall be mailed to the Surety on the Bond, or the lending institution named in the Irrevocable Letter of Credit (the "Bank"), whichever is applicable. If Contractor does not cure such default within seven (7) days of the date after notice was sent by City, City may declare a default of this Agreement and will notify the Contractor and the Surety or Bank of such declaration of default in writing and terminate the Agreement. 11.2.1 Within ten (10) days of such declaration of default, the Surety on the Bond shall, at its own cost and expense, rectify or cause to be rectified the default and also contract with a replacement contractor to be approved by City. Surety's replacement Contractor will assume the work of Contractor and complete performance of the work of the Project under the Agreement within thirty (30) days of City's approval of Surety's replacement Contractor. The Surety shall receive payment equal to what would have been paid the Contractor had the Contractor continued to perform the work under the Agreement, less any compensation paid to Contractor by City and less all sums due the City for any damages suffered or any expenses incurred, or both, by reason of Contractor's default. Alternatively, if applicable, City shall notify Bank that the Irrevocable Letter of Credit is required to be honored and payment immediately made to City. 8 11.2.2 If such Surety or Bank fails to perform any of its obligations as described above, the City may complete the Project, or any part of it, either by day labor or re-letting a contract ("Default Contract") for the same, and procure the equipment and the facilities necessary for the completion of the Default Contract, and charge the cost of same to the Contractor, the Surety, or both, together with the costs incident to such default. 11.2.3 In the event the City completes the Default Contract at a lesser cost than would have been payable to the Contractor under this Agreement, if the same had been fulfilled by Contractor, City shall retain such difference. Should such cost to the City be greater, then the Contractor, the Surety, or both shall pay the amount of such excess to the City. ARTICLE 12 BANKRUPTCY It is agreed that if the Contractor is adjudged bankrupt, either voluntarily or involuntarily, then this Agreement shall terminate effective on the date and at the time the bankruptcy petition is filed and Contractor will automatically be in default of this Agreement and the provisions of Article 11 will be enforced at City's discretion. ARTICLE 13 DISPUTE RESOLUTION 13.1 Venue; Fees. All claims, counterclaims, disputes and other matters in question between City and Contractor arising out of, relating to or pertaining to this Agreement, or the breach of it, or the services of it, or the standard of performance required in it, shall be addressed by resort to non-binding mediation as authorized under the laws and rules of Florida; provided, however, that in the event of any dispute between the parties, the parties agree to first negotiate with each other for a resolution of the matter or matters in dispute and, upon failure of such negotiations to resolve the dispute, the parties shall resort to mediation. If mediation is unsuccessful, any such matter may be determined by litigation in a court of competent jurisdiction in Broward County, Florida, or the Federal District Court of the Southern District of Florida and appropriate appellate courts for such venue and jurisdiction. In any litigation, the parties agree to each waive any trial by jury of any and all issues. In the event of any litigation which arises out of, pertains to, or relates to this Agreement, or the breach of it, or the standard of performance required in it, the prevailing party shall be entitled to recover reasonable attorneys' fees from the non-prevailing party, subject to the limits of this paragraph. Where the prevailing party is awarded compensatory damages from the non-prevailing party, the amount of attorneys' fees shall not exceed the amount of compensatory damages. If no compensatory damages are awarded, the prevailing party is entitled to reasonable attorneys' fees, which entitlement and award shall not exceed the total amount payable as Contractor's compensation under this Agreement. is 9 13.2 Operations During Dispute. 13.2.1 In the event that a dispute, if any, arises between the City and the Contractor relating to this Agreement, or its performance or compensation, the Contractor agrees to continue to render service in full compliance with all terms and conditions of this Agreement as required by the City. 13.2.2 Notwithstanding any other provisions in this Agreement, whenever any service provided by the Contractor fails to meet City's reasonable approval, the City will have the right to terminate the Agreement seven (7) days after the date when the written notice was sent by City of the deficiency, if Contractor has not cured such deficiency within that time. ARTICLE 14 MISCELLANEOUS 14.1 Legal Representation. It is acknowledged that each party to this Agreement had the opportunity to be represented by counsel in the preparation of this Agreement, and accordingly, the rule that a contract shall be interpreted strictly against the party preparing same shall not apply to this Agreement due to the joint contributions of both parties. 14.2 Records. Contractor shall keep such records and accounts and require • any and all subcontractors to keep records and accounts as may be necessary in order to record complete and correct entries as to personnel hours charged to this engagement, and any expenses for which Contractor may attempt to claim reimbursement. Such books and records will be available at all reasonable times for examination and audit by City and shall be kept for a period of three (3) years after the completion of all work to be performed pursuant to this Agreement. Incomplete or incorrect entries in such books and records will be grounds for disallowance by City of any fees or expenses based upon such entries. 14.3 Assignments, Subcontracts and Amendments. This Agreement, and any interests in it, shall not in whole or in part be assigned, subcontracted, transferred in any way or otherwise encumbered, under any circumstances, by Contractor without the prior written consent of City. For purposes of this Agreement, any change of ownership of or controlling interest in Contractor shall constitute an assignment which requires City approval. Violation of the terms of this paragraph shall constitute a breach of this Agreement by Contractor and City may, in its discretion, cancel this Agreement and all rights of Contractor under this Agreement will terminate. It is further agreed that no modification, amendment or alteration of the terms or conditions contained in this Agreement shall be effective unless contained in a written document executed by the authorized agents of the parties. 10 14.4 No Contingent Fees. Contractor warrants that it has not employed or retained any company or person, other than a bona fide employee working solely for the Contractor to solicit or secure this Agreement, and that it has not paid or agreed to pay any person, company, corporation, individual or firm, other than a bona fide employee working solely for Contractor any fee, commission, percentage, gift or other consideration contingent upon or resulting from the award or making of this Agreement. For the breach or violation of this provision, the City shall have the right to terminate the Agreement without liability and, in its discretion, to deduct from the Agreement price, or otherwise recover the full amount of such fee, commission, percentage, gift or consideration. 14.5 Notice. Whenever any party desires to give notice to the other party, it must be given by written notice, sent by certified United States mail, with return receipt requested, addressed to the party for whom it is intended. The places for giving of notice shall remain as set forth below until they shall have been changed by written notice in compliance with the provisions of this section. For the present, the Contractor and the City designate the following as the respective persons and places for giving of notice: City: Kenneth Koch, Building Official City of Dania Beach 100 West Dania Beach Boulevard Dania Beach, Florida 33004 • Copy to: Thomas J. Ansbro, Esq. City Attorney Weiss, Serota, Helfman, Pastoriza & Guedes, P.A. 3107 Stirling Rd. Suite 300 Fort Lauderdale, Florida 33312 Contractor: Philip Kaplan, President Durable Installations, Inc. 518 NW 77 Street Boca Raton, FL 33487 14.6 Binding Authority. Each person signing this Agreement on behalf of either party individually warrants that he or she has full legal power to execute this Agreement on behalf of the party for whom he or she is signing, and is authorized to bind and obligate such party with respect to all provisions contained in this Agreement. 14.7 Headings. Headings in this Agreement are for the convenience of reference only and shall not be considered in any interpretation of this Agreement. 14.8 Exhibits. Each Exhibit referred to in this Agreement forms an essential part of this Agreement. The exhibits, if not physically attached, are treated as parts of this Agreement and are incorporated in it by this reference. 11 14.9 Severability. If any provision of this Agreement or application of it to any person or situation shall to any extent be held invalid or unenforceable, the remainder of this Agreement, and the application of such provisions to persons or situations other than those as to which it shall have been held invalid or unenforceable, shall not be affected, and shall continue in full force and effect, and shall be enforced to the fullest extent permitted by law. 14.10 Governing Law. This Agreement shall be governed by the laws of the State of Florida with venue lying in Broward County, Florida. 14.11 Extent of Agreement. This Agreement represents the entire and integrated agreement between the City and the Contractor and supersedes all prior negotiations, representations or agreements, either written or oral. 14.12 Waiver. Failure of the City to insist upon strict performance of any provision or condition of this Agreement, or to enforce any right contained in it, shall not be construed as a waiver or relinquishment for the future of any such provision, condition or right, but the same shall remain in full force and effect. 14.13 Conflict. In the event there is a conflict between any of the terms in any of the documents contained in any Exhibit to this Agreement and any terms of this Agreement, the terms of this Agreement shall prevail. IN WITNESS OF THE FOREGOING, the parties have set their hands and seals the day and year first written above. CITY: CITY OF DANIA BEACH, A Florida Municipal Corporation ATTEST: dqi CHARLENE J SON, CITY CLERK R BERT H CHUNN, JR. , M YOR APPROVED FOR FORM AND CORRECTNESS: AN ATO, CITY MANAGER BY: 1 I ✓ THOMAS J. ANSBlPO, CITY ATTORNEY 12 CONTRACTOR: DURABLE INSTALLATIONS, INC. COMPANY NAME CORPORATE SEAL: By: —Z, �� (IF APPLICABLE) P p n President PRINT 4A E TITLE STATE OF FLORIDA COUNTY OF BROWARD BEFORE ME, an officer duly authorized by law to administer oaths and take acknowledgments, personally appeared Philip Kaplan, as President, and as , respectively, of Contractor, Durable Installations, Inc., a Florida Corporation, and acknowledged execution of the foregoing Agreement for the use and purposes mentioned in it and that the instrument is the act and deed of the Contractor. IN WITNESS OF THE FORE G G, I hav set my hand and official seal at in the State and County aforesaid on �( , 2002 y- f ! � Notary Public, State of Florida at Large 301 P Linde G. Fry 11 My Commission Expires: ���� (F� BSI �U avc 13 EXHIBIT "A" SPECIFICATIONS FOR FLOATING DOCKS @ WHISKEY CREEK NEW RIVER SOUND DANIA BEACH, FL 33004 I. Scope 1. This new construction and installation will take place on the existing docks in Whiskey Creek, New River Sound, located at the west side of the Municipal Parking Lot on Dania Beach, North Ocean Drive, Dania Beach, Fl. 2. The work shall consist of the fabrication and installation of 3 new 'T'- head floating docks, 1 rectangular floating dock, one handicap ramp, piles and associated hardware attached to existing wood docks. 11. General Conditions: ® 1. For all labor performed by the Contractor, the Contractor shall include the furnishing of all materials, labor, tools and equipment to complete the entire project. 2. The Contractor's submitted bid constitutes an understanding of all specifications and conditions related to this project. Contractor accepts all responsibility for correct application and installation of materials specified. 3: The specifications stipulated herein and as 'Notes' on plans by EDC Corp. dated 11/02/01 and revised 01/18/02 shall be considered apart of the contract. Any disagreements over any portion of these specifications must be brought to the attention of the Owner or Owner's representative who will determine any changes that must be made. IV- .Alternates 1. Alternates will be accepted as described in 'Notes' on EDC Corp. plan. V. Workmanship 1. All materials installed and all work performed shall be in compliance with and conformance to the South Florida Building Code, 1999 Broward County Edition, plans and specifications, and other agencies such as DPEP, DEP and Army COE. 1 2. Contractor shall assure that all work is performed in a workmanlike manner, and carried out so as to minimize any inconvenience to the residents. The Contractor shall maintain a full work force from the commencement of work to its completion. A qualified foreman shall be ® on the job site at all times. VI. Inspection: 1. Any application or installation which does not conform to this specification, The South Florida Building Code, or which does not meet with the approval of the Owner's representative shall be removed, corrected and/or repaired to meet specification. The Contractor shall be available for regular inspections throughout the work process. VII. Liaison: 1. The Building Official will be the Owner's designated representative. Contractor shall transmit all information pertaining to the job to the liaison and shall not permit unauthorized interference from the occupants or customers of the Owner's property, residents, or the Contractor's employees. VIII. Safety: 1. The Contractor shall be responsible for ensuring that employees read and follow all label directions and safety requirements recommended by the manufacturer of all products. 2. Contractor shall take appropriate measures to ensure protection of neighboring and surrounding properties, to include buildings, sidewalks, streets, and vehicles. Contractor shall arrange for barricades to keep vehicles from parking in front of the work areas, to keep pedestrian traffic out of these areas, and to direct pedestrian traffic away from the work areas. Barricades are to be installed at the commencement of the work and left until completion of the project. 3. Contractor shall protect all landscaping materials, walks, sidewalks, and other areas to protect them from damage due to construction-related activities. IX. Materials Storage 1. Bids shall be based on materials that meet requirements of specifications. 2. All materials shall be delivered to the job site in the manufacturer's original, sealed packaging with manufacturer's labels. 3. The Owner reserves the right, at his own expense, to take samples of any materials the Contractor plans to use and have it tested by an approved laboratory to confirm that the materials are as specified in this specification. 4. In the unlikely event that obviously defective or damaged material reaches the job site or damage to the material occurs from improper storage on the job site, it is the responsibility of the Contractor not to install this material. In the case of material that has obvious ® manufacturing defects, the material supplier should be notified immediately so replacement material can be supplied if the complaint is justified. Installation of defective material can 2 result in additional costs above the cost of supplying replacement material. If the contractor chooses to install material with obvious defects, this added cost is not the responsibility of the City. IX. CLEANUP 1. All trash and debris shall be cleaned from grounds and removed from site on a daily basis. 2. All equipment left on site shall be secured at the end of each workday. 3 EXHIBIT "B" PUBLIC CONSTRUCTION BOND BY THIS BOND, We, as Principal and , a corporation, as Surety, are bound to THE CITY OF DANIA BEACH, FLORIDA, herein called Owner, in the sum of Dollars ($ ), for payment of which we bind ourselves, our heirs, personal representatives, successors, and assigns,jointly and severally. THE CONDITION.OF THIS BOND is that if Principal: 1. Performs the contract dated , 199 , between Principal and Owner pertaining to , the contract being made a part of this bond by reference, at the times and in the manner prescribed in*the contract; and 2. Promptly makes payments to all claimants, as defined in §255.05(1), Florida Statutes, supplying Principal with labor, materials or supplies, used directly or indirectly by Principal for the prosecution of the work provided for in the contract; and 3. Pays Owner all losses, damages, expenses, costs and attorney's fees, including appellate proceedings, that Owner sustains because of a default by Principal under the contract, including, but not limited to, all losses, damages, expenses, costs and attorney's fees, including appellate proceedings that Owner sustains as a result of Principal's delayed completion of the contract (i.e., liquidated or actual • damages for delayed completion), failure to provide, or breach of any warranties or guarantees required by or given under the contract, failure to provide accurate as-built drawings, breach of the indemnification clauses in the contract, failure to maintain continuously the insurance requirement required by the contract, failure to pay all royalties or license fees or failure to provide for safety of persons and property; and 4. Performs the guarantee of all work and materials furnished under the contract for the time specified in the contract, then this bond is void; otherwise it remains in full force. Any changes in or under the contract documents, compliance or noncompliance with any formalities connected with the contract or to the contract, or Principal's allegation that its performance under the contract was prevented or frustrated by the Owner or that Owner breached the contract, the changes does not affect Surety's obligation under this bond. DATED ON , 199 (Name of Principal) By: (As Attorney in Fact) (Name of Surety) ®o 4 CITY OF DANIA BEACH BID SUBMITTAL FOR FLOATING DOCKS WHISKEY CREEK NEW RIVER SOUND TO: City Commission City of Dania Beach proposes to: Construct and install three (3) `T'-head floating docks, one (1) rectangular floating dock, one handicap ramp and piles at the existing docks located at the west side of the municipal parking lot at North Beach Road for this amount: TOTAL BID $ NOTE: BID FROM MUST BE SIGNED WITH THE FIRM'S NAME,AND BY AN OFFICER OF THE COMPANY OR EMPLOYEE HAVING THE AUTHORITY TO BIND THE COMPANY OR FIRM BY SIGNATURE. Submitted this day of , 2000 Company Name: Address: Telephone: Printed name of company representative Signature of company representative Title Sworn to and subscribed before me this day of 12000,by ,who is(personally known or showing identification). and(did/did not)take an oath. Notary Public,State of Florida,County of i AGENDA REQUEST FORM CITY OF DANIA BEACH AGENDA ITEM NO. 1. DATE OF COMMISSION MEETING: MAY 14, 2002 2. DESCRIPTION OF AGENDA ITEM: BID AWARD 3. COMMISSION ACTION BEING REQUESTED: Adopt Resolution or Ordinance ❑ Expenditure [ ] Award Bid/RFP [X] Presentation ❑ General approval of item ❑ Continued from meeting ❑ Other(please explain) ❑ 4. SUMMARY EXPLANATION & BACKGROUND: AWARD BID FOR CONSTRUCTION OF FLOATING DOCKS AT WHISKEY CREEK TO LOWEST RESPONSIBLE, RESPONSIVE BIDDER, DURABLE PRODUCTS, INC. IN THE AMOUNT OF $49,975.00. 5. ATTACHED EXHIBITS AND ADDITIONAL BACKUP MATERIALS (PLEASE LIST): MEMO TO CITY MANAGER (APRIL 23,2002), 6 BID PROPOSAL FORMS 6. FOR PURCHASING REQUESTS ONLY: Dept: Amount: $ Fund: GENERAL: ❑ WATER: ❑ SEWER: ❑ STORMWATER: ❑ Account name: Account#: Finance Director Approval: Date: Submitted by: Kenneth H. Koch, Building Official Date 04/23/02 Growth Management Department City Manager Date MEMORANDUM TO: Ivan Pato, City Manager FROM: Ken Koch, Building Official RE: Bid Award, Whiskey Creek Floating Docks Date: April 23, 2002 As you will recall, this project was put out for bid once before (in January of this year), and all bids were rejected as they were all substantially higher than the grant amount available of $49,000.00. The specifications were then modified to allow for more competitive bidding, with no reduction in quality. The new set of bids was opened on April 22, 2002. They were 6 respondents. They are: ® Custom Built Marine, Inc. $77,489.00 • Shoreline Foundations, Inc. $73,000.00 ® Morrison Builders $69,269.00 o KMI Marine, Inc. $65,892.00 ® Subaqueous Services, Inc. $59,069.00 ® Durable Installations, Inc. $49,975.00 All bidders were properly responsive and responsible. Although the lowest bid is still $975.00 higher than the grant money available, I believe that we should go with the lowest bidder and move forward with this project. I do not believe it to be possible to get the cost any lower than this. The lowest bid on the first round was $59,069.00. 1 recommend that we award the contract to Durable Installations, Inc. I will place this matter on the Commission agenda for the meeting of May 14, 2002. Bid Award Floating Docks.doc INVITATION TO BID CITY OF DANIA BEACH, FLORIDA Notice is hereby given that the City Commission of the City of Dania Beach, Florida, is seeking sealed bids for: CONSTRUCTION OF FLOATING DOCKS WHISKEY CREEK NEW RIVER SOUND located at west side of municipal parking lot, north beach road, Dania Beach, FI 33004. Bid packages containing plans and specifications may be obtained from the Office of the City Clerk, 100 W. Dania Beach Boulevard, Dania Beach, Florida 33004, or by calling (954) 924- 3624. For additional information regarding construction (only) of the project, please contact Ken Koch, Building Official, at (954) 924-3650. For general information other than construction or for location, please contact Captain Glenn Morris at (954) 924-3696. • Bids will be accepted until 3:15 p.m. on Monday, April 22, 2002, in the Office of the City Clerk, City Hall, 100 W. Dania Beach Blvd., Dania Beach, FI 33004, and will be publicly opened at 3:30 p.m. in the city's conference room. Envelopes must be sealed and plainly marked: "Bid For Floating Docks-Whiskey Creek" Bid packages must consist of completed proposal, references, and either a business card or letterhead with company name, address, contact person and phone number. The City of Dania Beach reserves the right to reject any and all bids, to waive any and all informalities or irregularities, and or reject all or any part of any bid as it may deem to be in the best interest of the citizens of the City of Dania Beach. The City of Dania Beach encourages participation by SDBE firms. //Charlene Johnson, CMC City Clerk Sun Sentinel publication: 4/3/02 and 4/10/02 • 1 "ura le histilations Specializing in Marine and Outdoor Construction " 518 NW 77th Street Boca Raton,Florida33487 ITY OF DANIA BEACH is 1ID SUBMITTAL FOR Flip Kaplan,President 1-561-241-4667 FLOATING DOCKS State Lic.#CGCA 10072 1-561-241-4591 Fax Line Fstablished 1977 1-800-244-1373 In Florida WHISKEY CREEK NEW RIVER SOUND TO: City Commission City of Dania Beach .jG- proposes to: Construct and install three (3) 'T'-head floating docks, one (1) rectangular floating dock, one handicap ramp and piles at the existing docks located at the west side of the municipal parking lot at North Beach Road for this amount: o� TOTAL BID $ 4LI, q 1 NOTE: BID FROM MUST BE SIGNED WITH THE FIRM'S NAME,AND BY AN OFFICER OF THE COMPANY OR EMPLOYEE HAVING THE AUTHORITY TO BIND THE COMPANY OR • FIRM BY SIGNATURE. Submitted this 2Z day of �' 2002 Company Name: DV124(1216 I:.TIA)"eAtw'is, .� C- Address: p rram•� Telephone: 6 � ^ R, �yj`•� $'� Printede/of company representative Signature f om any representative Title Sworn to and subss ibed before me this�day of yZ r-, �- 2002,by �"+ who is(personally known or showing ntifi tion . and(did/di )take an oath.4 G 0• S l• y yZ•f.) Notary Public,State of Florida, ounty of A,%.. 4/c,4 � 1"i'/'9 A D Arl . .l Helen M Hargcdon • '*: r MY COMMISSION#CC784212 EXPIRES ,•, °• October 19,2002 , BONDED TNRU TROY FAIN MURANCE INC CITY OF DANIA BEACH BID SUBMITTAL FOR FLOATING DOCKS WHISKEY CREEK NEW RIVER SOUND TO: City Commission City of Dania Beach Subaqueous Services. Inc. proposes to:,Construct and install three (3) 'T'-head floating docks, one (1) rectangular floating dock, one handicap ramp and piles at the existing docks located at the west side of the municipal parking lot at North Beach Road for this amount: TOTAL BID $ 59 , 069. 00 Fifty nine thousand sixty nine dollars and no cents. NOTE: BID FROM MUST BE SIGNED WITH THE FIRM'S NAME,AND BY AN OFFICER OF THE COMPANY OR EMPLOYEE HAVING THE AUTHORITY TO BIND THE COMPANY OR FIRM BY SIGNATURE. • Submitted this 22 day of April , 2002 Company Name: Subaqueous Services, Inc. Address: 4201 Kean Road, or Lauderdale, FT,ori�dag33314 Telephone: 954-581 -281 0 Owen K. Sloan Printed name of company representative Signature of co any representative President Title Swom to and subscribed before me this 2 2 day of April 2002,by O/w,pn K. S 1 who is(personally known or showing identification). nd i / id not)t ce a th. 4- c Notary Public,State of Florida,County of Broward ��o'pra''ty, Alicia .A. Cantrell ISConmisEdnn#OC 995534 4= Expim Menh 9.2m �y'OOF fS% +, u • n,,,,, r� Bonding Go.JuL MARINE CONSTRUCTION �i�+•-�_ • Seawalls • Docks • Marinas • Rip Rap Marine, Inc. Boatlifts • Engineering t may be terminated by City if Contractor fails to Kenneth S. Vella® President and reasonable approval, after City sends written notice 927-4917 12 and Contractor does not cure such deficiency within —ic#21100/99-1629X (954) 27 Office:(305) - lch notice. In such event, the Contractor shall be paid ' o.Box 221291 Fax:(305)685-6032 ; made toward completion of the Project, if such iollywood, FL 33022 e-mail:KMlmarine@aol.com and reasonable approval, which approval will not be u1uC;d3U11au1y WILWICIu. w wc event that the Contractor abandons the work specified in this Agreement or causes it to be terminated, Contractor shall indemnify the City against any loss pertaining to its abandonment up to a maximum of the amount to be paid under this Agreement. All finished or unfinished materials, documents and reports prepared by Contractor shall become the property of City and shall be delivered by Contractor to City before payment, if any, is made to Contractor by City. ARTICLE 4 COMPENSATION AND METHOD OF PAYMENT 4.1 City agrees to compensate Contractor, as follows, no later than twenty (20) business days after the City Building Official or his designated representative approves all of Contractor's completed Project work pursuant to the provisions of this Agreement: TOTAL AGREEMENT AMOUNT: $ �5. ® Otis C�f� iS uStN � FWftT(11)(4 'DOCK ME4NUFAGTi721:10 �7/ �,th7o� -Doc Project completion shall be idenced by a writing to that effect, issued by the 04AK CE City Building Official and given to the City Clerk. The total compensation above may not be exceeded without a written amendment to this Agreement executed by the authorized agents of both of the parties. 4.2 Payment will be made to Contractor at: A AA Kf4I MAXiIJE fN� PD. f X ZZ I Z9 1 tIoLI y 000 P-L �30 2Z 3oS &BA-711 Z 4.3 The making and acceptance of the work shall constitute a waiver of all claims by the City except for any or all claims arising from the guarantee set forth above, unsettled liens, lawsuits, deficiencies or faulty work appearing within one (1) year after final payment, or from any variations from the requirements of the Specifications for the Project. The acceptance of payment shall constitute a waiver of all claims_ against City by the Contractor. (4) CITY OF DANIA BEACH BID SUBMITTAL FOR FLOATING DOCKS WHISKEY CREEK NEW RIVER SOUND TO: City Commission City of Dania Beach Morrison Builders, Inc. proposes to: Construct and install three (3)"T"- head floating docks, one (1) rectangular floating dock, one handicap ramp an piles at the existing docks located at the west side of the municipal parking lot at North Beach Road for this amount: • TOTAL BID: $69,269.00 NOTE: BID FORM MUST BE SIGNED WITH THE FIRM'S NAME, AND BY AN OFFICER OF THE COMPANY OR EMPLOYEE HAVING THE AUTHORITY TO BIND THE COMPANY OR FIRM BY SIGNATURE. Submitted this 19_day of April, 2002 Company Name: Morrison Builders,Inc. Address: 2765 SW 36th Street. Dania Beach FL Telephone: 954-583-8500 U cruelo�� Prin ed name of company representative Signature of cQrnpany representative DRF5��t- 'N?nT Ti le Sw•om to and subscribed 71(Ci me this day of 0 1 L.2002 by � n ' 1 M',who is(personally known or showing identification). State of Florida,County of_`Ss� �cl l Cynthia Ann Wood MY COMMISSION# CC962953 EXPIRES October 20,2004 • iR;� BONDED THRU TROY FAIN INSURANCE INC S.MICHAEL BETANCOURT �. Vice President y Deep Foundations rY OF DANIA BEACH Sine Foundation,Inc. Marine Construction ID SUBMITTAL FOR Phone: (954)985-046 FLOATING DOCKS 2 WHISKEY CREEK 2781 S.W.56th Avenue Fax: (954)985-046 Pembroke Park,FL 33023 www.shorelinefoundabon.com VEW RIVER SOUND CGCO58114•E1922 michael@shorelinefoundation.com i TO: City Commission City of Dania Beach �re.liEr, q->-ndafion , 1nC . proposes to: Construct and install three (3) 'T'-head floating docks, one (1) rectangular floating dock, one handicap ramp and piles at the existing docks located at the west side of the municipal parking lot at North Beach Road for this amount: TOTAL BID $ 3, oa0 NOTE: BID FROM MUST BE SIGNED WITH THE FIRM'S NAME,AND BY AN OFFICER OF THE COMPANY OR EMPLOYEE HAVING THE AUTHORITY TO BIND THE COMPANY OR FIRM BY SIGNATURE. Submitted this DD day of 2002 Company Name: Seel Ine �cX1C'14�1 r�l , 1 f-1C Address: D-1 I 5U'-n AVf—"� pi°-nbv-OY_2. �-t'r1`-, , GL_ 33bZ3 Telephone: q •9�S C�4 la G �S.m►cr-�ge.l ncr-���-�- Printed name of company representative Signature of company representa ive U/ Clan-�- Title Swornto and subscribed beffoore,me thisclday of 2002,by t /• �44��` 'dam �(1�.CJ1�who is(perso Ilv known or showing identification). and(did/did not take an Ith. Notary Public,State of Florida,County of r0WApa�- / j �PRN PVe OFrIC 6"BEIIYACOVA - x COMMISSION NU MBEi CC915081 p " 7 e— Con5 uchonAS deP► coed Q � drOW I n pirepIcki-td by corporQ-fion� Flo t3►d Sib rat-�-1 fbiL L ' 1 S' C1 vcrcab 1 e clocr�c. a P N � Y'-1'✓JGI GJCG lk.l.'11 LIMYlr-1 DCrlk-71 L'll llj ?1JC'1L�OLOt'L i'IV.`1_'_' Vt_IL �1 CITY OF DANIA BEACH RID SUBMITTAL FOR FLOATING DOCKS WHISKEY CREEK NEW RIVER SOUND TO: City Commission City of Dania Bea ch''rr A $�rV � U� ►-�(r • proposes to: Construct and install three (3) 'T'-head floating docks, one (1) rectangular floating dock, one handicap ramp and piles at the existing docks located at the west side of the municipal parking lot at North Beach Road for this amount: a TOTAL BID NOTE:BID FROM MUST BE SIGNED WITH THE FIRM'S NAME,AND BY AN OFFICER OF THE COMPANY OR EMPLOYEE HAVING THE AUTHORITY TO BIND THE COMPANY OR FIRM BY SIGNATURE. Submitted this al day of e+Zt j ,2002 Company Name: 6 y5'i-err► U - /.��r'i n�, royl!s�ro&111 r)N f re— Address:31-T 0 SE L Jl4,+e-6--*-- VDU Lc 3 7 Telephone: )7 z. 2-k k Z P\nnt� name of comp y representative S net re o company rep sentative Y Title m to subscribed before me W6 / day of 1 t ,2002,by rr► Alt vo .who{8(personally known or showing fdentifica6on). id/did not)WO Notary Puwic,State of Florida,County of MARGY BARZ Op MY COMMISSION ACC 9368% or �oP� EXPIRES:May 13,2004 1-0003.NOTARY FL Notary Samoa 6 Bonding bux