Loading...
HomeMy WebLinkAboutR-1995-004 ` �`'n `ys` �.:'� x r ` .._.� ..._ r w afr v. sg v�*^�J •Y��S{ i • • s�)q ua eFµ.`�tfki gjxz 1 , A b 'via � tt��titi P r , n RESOLUTION NO. 04-95 1 f fps, t°ins a"3, A RESOLUTION OF THE CITY OF DANIA, FLORIDA, APPROVING � FL t AGREEMENT BETWEEN JEFFERY GROSS/ASSOCIATES/ ARCHITECTS, P.A., AND THE CITY OF DANIA, RELATING TO x g CONSTRUCTION OF A NEW CONFERENCE ROOM AT DANIA CITY HALL; AND PROVIDING FOR AN EFFECTIVE DATE. t< , BE IT RESOLVED BY THE CITY COMMISSION OF THE CITY OF DA NIA, t FLORIDA: Sy�74ti� ylf 9 Section 1 That that certain Contract between Jeffery Gross/Associates/ t Architects, P.A., and the City of Dania, relating to construction of a new conference room at Dania City Hall, a copy of which is attached hereto as Exhibit "A", be and thef x ` same is hereby approved. A i r 3ec514n 2- That all resolutions or parts of resolutions in conflict herewith be and the same are hereby repealed to the extent of such conflict. r t . Section 3, That this resolution shall be in force and take effect immediately upon its passage and adoption. r PASSED and ADOPTED on this 10th day of January , 1995. ;TY ss ,y AF Kp1�,+ f+ ' ATTEST: Mayor Commissioner F City Clerk' Auditor ' APPROVED AS TO FORM & CORRECTNESS A" f, By: Frank C. Adler, City Attorney 4 R� Y ` Resolution No. 04-95 ill Y i!'�rA: A4 I ' rll r r t1 AGREEMENT BETWEEN OWNER AND ARCHITECT n, , H, t AGREEMENT ' r ' made of the day of in the year of Nineteen Hundred and Ninety-four k r v BETWEEN the Owner: i City of Dania \ 100 West Beach Boulevard N� y+ , Dania FL 33004 t'{ ',es�" '�tw<rl� and the Architect: s °un: gyp} Jeffery Gross/Associates/Architects P.A. +° 1816 Sherman Street Hollywood, Florida 33020 ° Y for the following Project: c ;+' Construction documents, Bidding and Construction Administration for a proposed conference room at the existing n 4 " �s r\ city of Dania City Hall site consisting of approximately 1,4SS square feet. enclosing the existing garden area adjacent to *x the employee's lounge. The Schematic and Design Development have been prepared under a previous contract. the Owner and the Architect agree as set forth below. L I R ATCE 1 rMµ A , } : rya ARCHITECT'S SERVICES AND RESPONSIBILITIES #r lr The Architect's Basic Services are as described below and in Article 10. 1.1 BASIC SERVICES 5{K YT' t 1.1 CONSTRUCTION DOCUMENTS " y syf . I Based on the previous approved floor plan and program, the Architect shall prepare, for approval by the Owner, - a, $ Construction Documents consisting of Drawings and Specifications setting forth in detail the requirements for the construction of the Project. t 1.1.2 The Architect shall assist the Owner in connection with the Owner's responsibility for filing documents required to �, > b n e i,K obtain a building permit from the City ofDania. a 1.4 ADDITIONAL SERVICES ° 'ri`` " 1.4.1 Additional Services shall be provided if authorized or confirmed in writing by the Owner or if included in Article 10, a.S and they shall be paid for by the Owner as provided in the Agreement. �4�+ } 1.4.2 If the services of a Civil Engineer, Landscape Architect or other Professional not stated in the Opening *l mar Article I, is required or requested by the Owner, the cost of such services shall be directly billed to the Owner. Saidph of Professional shall work directly with the Architect to complete the project. Architect's services provided in connection with other Professionals required or requested by the Owner shall be considered an additional service. L� 1.4.3 The following two items shall be also considered an additional service. An estimate of the hours required to perform w Lct r s these services are attached: �u 1.4 BIDDING OR NEGOTIATION } ' r 1.4.1 The Architect, following the Owner's approval of the Construction Documents shall assist the Owner in providing clarifications and/or interpretations of the contract documents for the owner selected contractors (maximum of three) submitting bids or negotiating a contract for construction. G 1.4.2 CONSTRUCTION PHASE-ADMINISTRATION OF THE CONSTRUCTION CONTRACT 1.4.2.1 The Construction Phase will commence with the award of the Contract for Construction and shall extend for Ninty ';ts (90) days. If construction extends past the time provided and the Architect is requested by the owner to continue with the •E Administration Of The Contract, it will be considered an Additional Service. "- 1.4.2.2 The Architect shall visit the site approximately once a week during the construction period. On the basis of such �? \ s' on-site observations, the Architect shall keep the Owner informed of the progress and quality of the work, and shall endeavor to guard the Owner against visually noticeable defects and deficiencies in the work. 1.4.2.3 The owner shall provide a representative to coordinate with the contractor, therefore maintaining all operations ro* a to them baing provided to the Architect. working as required by the owner and landlord. That representative shall review and approve all contractors requests prior * EXHIBIT ►► v i t• tnr. Tt prgig� �u 4 7 Y pl P ,Y bra N Z5t ! t N Page number 2 of 4 � 1 t 1.4.2.4 The Architect shall respond to the contractors requests, after owner's review, in writing and will submitted to him in writing. The contractor, upon owner's a tiw. Architect is visiting the site. Response to those requests will be verbally provided on site, if able, and latersubm fled ashen approval shall submit his questions once a week at the time the writing for the record. t 1.4.2.5hniq The Architect shall not have control or charge of and shall not be responsible for construction means, methods, techniques sequences or procedures, or for safety precautions and programs in connection with the Work, for the acts or omissions of the Contractor, Sub-contractors or any other persons performing any of the Work, or for the failure of an them to carry out the Work in accordance with the Contract Documents. 1.4.2.6 The Architect shall at all times have access to the Work wherever it is in preparation and Progress y of 1.4.2.7 The Architect shall review and recommend a "' construction documents. Shop drawings are only approval or disapproval for only shopdrawings g m ut dg} Architect's recommended a awings requested in the g it reviewed for conformance with the design concept of the work. The ,tk ,t F !• component. Shop drawing pandvor�ubm specific bmitted to of indicate that are not requested on the E h approval of an assembly of which the item is a r Documents shall not be reviewed unless directed by the Owner. Review of such shall be d; ' ii Y, (�;+. �i'nK`�� Service. Construction a 'phi t Ser considered an Additional 2.8 The extent of a k, the duties, responsibilities and limitations of authority of the Architect during construction shall not be modified or extended without written consent of tite Owner, and the Architect. >2 it 1.5 TIME 5.1 Y a 1 The Architect shall perform services as expeditiously as is consistent with professional skill and care and the orderly Progress of the Work. ARTICLE 2 k . THE OWNER'S RESPONSIBILITIES +t The following services and responsibilities, and any others so indicated in Article 10, shall be undertaken by the Owner. 4tt �xf 2.1 The Owner shall provide full information, including developing a program as per 1.1, which shall set forth the + Owner's design objectives, constraints and criteria. 2.2 The Owner shall furnish a legal description and a certified land survey of the site and the services of soil engineers or h ` other consultants when such services are deemed necessary by the Architect. 1 �'. The Owner shall furnish chemical and other Arc laboratory tests, inspections and reports as required by law or the Architect. S a the The Owner shall furnish all legal, accounting and insurance counseling services as may be necessary at the time for the Project. 2.5 The services, information, surveys and reports required by Paragraphs 21 through 2.4 inclusive shall be famished at ; the Owner's expense, and the Architect shall be entitled to rely upon the accuracy and completeness thereof. 2.6 The Owner shall furnish required information and shall render a q $td s for the orderly progress of the Architect's services and of the Work. ,tu, approvals and decisions as expeditiously as necessary 4y� a r „ , ARTICLE 3 PROBABLE COST 3.1 DEFINITION << Fir? a il �1,n 3.1.1 The Probable Cost shall be the total cost or estimated cost to the Owner of all elements of the Project designed by 4f the Architect. s 14,'� 3.1.2 The Probable Cost shall include at current market rates, including a reasonable allowance for overhead and profit, GS the cost of labor and materials furnished by the Owner and any equipment which has been designed, specified, selected or ih , + kati? specially provided for by the Architect. 'y g h 3.1.3 Probable Cost does not include the compensation of the Architect and the Architect's consultants, the cost of the tyAq�!s land, rights-of-way, or other costs which are the responsibility of the Owner as provided in Article 2. 54 }3.2 RESPONSIBILITY FOR PROBABLE COST a r t"" 1° 3.2.1 It is recognized that neither the Architect nor the Owner has control over the cost of labor, materials or equipment u over the Contractor's methods of determining bid prices, or over competitive bidding, market or negotiating conditions. 5 u 4 a' Accordingly, bids or negotiated prices shall not be considered the responsibility of the Architect .4 3.2.2 No fixed limit of Construction Cost shall be established as a condition of this Agreement by the furnishinn t ' or establishment of a Project budget. g, Proposal + •" �>':a it r �}x t -ir ar ARTICLE 4 rt `�,,°t,�M•� y ien ��kpi�a�`��_"t�•�r r Il 1 4 MEi Page number 3 of 4 PAYMENTS TO THE ARCHITECT .sl 4 ✓rY��fi, t et !a2 r' 4.1 An initial payment as set forth in Paragraph 9.1 is the minimum payment under this Agreement. a < wit Subsequent payments for Basic Services shall be made monthly and shall be in proportion to services performed a, within each Phase. 4.3 Reimbursable Expenses include actual expenditures made by the Architect in the interest of the Project for: S 1 expense of transportation and living expenses in connection with out-of-town travel, authorized by the Owner, t Efi y 2 long distance communications, t .3 fees paid for securinga .4 re roductions, approval of authorities having jurisdiction over the Project, 5 postage and handling of Drawings and Specifications, � .6 renderings and models requested by the Owner, 1" r��Eigo' 7 expense of overtime work requiring higher than regular rates, if authorized by the Owner, C OWnexpense of any additioner. al insurance coverage or limits, including professional liability insurance, requested by the 4.5 Payments on account of the Architect's Additional Services and for Reimbursable Expenses as defined in Paragraph a� 4.4 shall be made monthly upon presentation of the Architect's statement of services rendered or expenses incurred. e 4.6 If the Project is suspended or abandoned in whole or in part for more than three months, the Architect shall be `!s r, =i compensated for all services performed prior to receipt of written notice from the Owner of such suspension or r S abandonment, together with Reimbursable Expenses then due and all Termination Expenses as defined in Paragraph 7.4. If M d1 the Project is resumed after being suspended for more than three months, the Architect's compensation shall be equitably s adjusted. e.r. ARTICLE 5 1. OWNERSHIP AND USE OF DOCUMENTS h t 2�rk , rit 5.1 Drawings and Specifications as instruments of service are and shall remain the property of the Architect whether the �aa Project for which they are made is executed or not. 5.2 Submission or distribution to meet official regulatory requirements or for other purposes in connection with the r ,^t Project is not to be construed as publication in derogation of the Architect's rights. { p P ARTICLE 611 .�� ARBITRATION 6.1 All claims, disputes and other matters in question between the parties to this Agreement, arising out of or relatingto i ,F nr TYtS v j this Agreement or the breach thereof, shall be decided by arbitration in accordance with tlue Construction Industry Arbitration Rules of the American Arbitration Association then obtaining unless the parties mutually agree otherwise. No arbitration, arising out of or relating to this Agreement, shall include, by consolidation, joiner or in any other manner, any "r additional person not a party to this Agreement except by written consent containing l � ryy$fr 1� I and signed by the Architect, the Owner, and any other person sought to be joine Agreement d. Any consent a specific ref arbitration involving to thus Agreeme nt n, $> additional person or persons shall not constitute consent to arbitration of any dispute not described therein. This an Agreement to arbitrate and any agreement to arbitrate with an additional person or persons citify consented to by the parties a" 4 to this Agreement shall be specifically enforceable under the prevailingr yi ti m 6.2 In no event shall the demand for arbitration be made after the date when institution of legal or equitable proceedings arbitration law. based on such claim, dispute or other matter in question would be barred by the applicable statute of limitations. 6.3 The award rendered by the arbitrators shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. ARTICLE 7 " TERMINATION OF *;vFt AGREEMENT 7.1 This Agreement may be terminated by either party upon seven days' written notice should the other party fail {aE 1 substantially to perform in accordance with its terms through no fault of the party initiating the termination. 9jYF, 7.2 This Agreement may bPW e terminated by the Owner upon at least seven days' written notice to the Architect in the > 1 event that the Project is permanently abandoned. taus "4g`7.3 In the event of termination not the fault of the Architect, the Architect shall be compensated for all services performed to termination 6 � >, date, together with Reimbursable Expenses then due. r ARTICLE 8 u r� ri y. �s�t•. fir, I ry �rxty 1 A r� }• - Y x 1 +4 ` .., j k>Y i' KS SAY} Y pi v 1 r': 'r:-,•__'. 1d w ✓rr :c lft h'k'w, J >r z yii � r r1 v =a r 1 7 Page number 4 of 4 ` £s MISCELLANEOUS PROVISIONS 81 overned ' k 8.2 Ahl between nthe partiebto tills Agreement:law as to ell acts ohe r fa lu of �esto act 6 applicable statute t limitations shall commence to run and any alleged cause of action shall be deemed top have accrued + y either party to this Agreement, any r X W in any and all events not later than the relevant Date of Substantial Completion of the Work, and as to any acts or failures to act occurring after the relevant Date of Substantial Completion, not later than the date of issuance of the final Certificate ex t for Payment. 8.3 The Owner and the Architect, respectively, bind themselves, their partners, successors, assigns and legal representatives to the other party to this Agreement and to the partners, successors, assigns an i + . such party with respect to all covenants of this Agreement. Neither the Owner nor the Architect shall assign, sublet or �14 transfer any mterest in this Agreement without the written consent of the other. g d legal representatives of8.4 This Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes all prior negotiations, representations or agreements, either written or oral. This Agreement d t be amended e r written instrument signed by both Owner and Architect. Y only by r1 ARTICLE 9 , a55 BASIS OF COMPENSATION ` � yr�l� �• y } 1 g The Owner shall compensate the Architect for the Services provided, in accordance with Article q, Payments to the v Architect, and the other Terms and Conditions of this Agreement, as follows: * f' a" x 9.1 AN INITIAL PAYMENT OF 1 p tl N Al Two Thousand & 00/100 DOLLARS ($2000.00) shall be made upon execution of this Agreement and credited to the final r payment of the Owner's account. tk{ t 9.2 BASIC COM PENSATION 9.2.1 FOR BASIC SERVICES, as described in Paragraphs 1.1 or identified as such in Article 10, Basic Compensation shall be a stipulated sum of J' SIX THOUSAND FIVE HUNDRED EIGHTY & 00/100 DOLLARS ($6,580.00). 7�,,�; ir't 9.2.2 Payments for Basic Services shall be made as provided in Subparagraph 4.2. wx ^9.3 FOR ADDITIO, i � L SERVICES provided under Paragraph 1.5 or identified as such in Article 10, compensation shall y +ttt be computed as follows. All staff members time at the fixed rate Seventy & 00/100 dollars per hour($70.00/hood 9.4 Payments due the Architect and unpaid under this Agreement shall bear interest from the date payment is due at the " legal rate prevailing at the principal place of business of the Architect. 9.5 The Owner and the Architect agree in accordance with the Terms and Conditions of this Agreement be e IF THE SCOPE of the Project or of the Architect's Services is changed materially, the amounts of compensation shall g nt that wu f be equitably adjusted. 9.5.2 IF THE SERVICES covered by this Agreement have not been completed within six (6) months of the date hereof p through no fault of the Architect, the amounts of compensation, rates and multiples set forth herein shall beequitably' adjusted, l' ` ARTICLE 10 r OTHER CONDITIONS OR SERVICES of r°x ��� •1 + N 10.1 The Architect will provide two complete sets of documents to the Owner. t , Z : 10.2 Cost of Reproductions requested by the owner shall be reimbursed to the Architect at the following rates: , Whiteprints (24"x36") Q a " Copies (8.5"x11"/14") (off $1.50 per sheet $0.50 per copy 10.3 The following additions services shall have a not to exceed hour cap as shown as long as the scope of services does of BIDDING OR NEGOTI not change from the schedules services. " +,,,+ of as described in article 1.4-19 hours � � Y " CONSTRUCTION PHASE-ADMINISTRATION OF THE CONSTRUCTION CONTRACT as describe in article 1.4.2- Jets 75 Hours 'taS o 1a 1' M fraty� tt "•�*�+h•�r Y ,F y r.Xn ..... r .05,- .r.:_.. _ .. � ...... _ .fi:.d9�r..wn•Y.C(Ai?:-a, ... r?.. 1 T r f� f 1 p. , � a >I x1n, .y` —k `^'a A.1 .Wi .Y� a S1�sz„t��,1�,pxja�fk 1�Y� P, i' :SDIJ P)� r� t ,ti a +kt{� , j 1eC' ei p 4 t. y�^ rt 1, CITY OF DANIA ���`tr,.a CONFERENCE ROOM SCHEDULE OF SERVICES ESTIMATED HOURS SERVICES ,sue��a,�i�r r�'yF`• o Hours Totals 1.2 CONSTRUCTION DOCUMENT PHASE ' p y,hr'"(y,"M�';o t1Mf 94 1 .2.1 Development of Architectural Construction Drawings "s y, a, c; (Construction Drawings will be on 24"x36" sheets) 'y 01 Site Location Plan No Scale First Floor Plan 4 03 Roof Plan 1/4"= 1'-O" Wall Sections 4 crdrr 3/4" 12 fa.06 Building Elevations '1/4" =1' 0"r,jit ' .08 Door Schedule Hardware Schedule & Details 8 09 Finish Schedule & Details 4 3 L;s t. 3 t,Gfi as f* .10 Specifications 4 �ryir�t 10 3 1.2.2 Development of Structural Construction Documents 3; a .01 Foundation Plan 15 X , .I Roof Framing Plan 1/4" = 1'-0" ,x .03 Footing, Column & Beam Schedules 1/4" = 1 '-0" I as .04 Details & S *'� ,r b, pecifications 3/4" 1.2.3 Development of Mechanical Construction Documents 15 1 ; g 01 First Floor Plan 1/4" .02 Schedule & Details 1 1/411= 7'-04, ' re Documents 1.2.5 Development of Electrical Construction D Ay, 15 " t ft' ,, 01 First FloorI All Plan r, r ,r .02 Luminaire and Pan Schematic el Schedules, Schtic t 4 h{ 4 / Diagram and Electrical Calculations s ��jN,"� BIDDING OR NEGOTIATION PHASE 1-9 +K j 01 Preparation and distribution of Bidding ' Documents 3 02 Responses and explanation to 3 Bidders 12 over a two week bidding Period. k .03 Receipt of requested Bids ( T. 04 Analysis and recommendation of Bids 1 ;. I 05 Assistance in preparation of Construction 3 s a r t y Y 532�� 10 to lxv R NR.'7y '1'�1r�jyr'F'y I i r�� t, \� x it �..,r� .��� v� ' ������rT,Rr 4•:J10 41°, 5S t xsSl F4.h�"�1.1S It, ri grr?; Contract 1.4 1 h i CONSTR JCTION ---U1 Processing of S t �f�'it Lhop Drawings and/or Submittals (5) re a tests, barjoist, a/c unit electrical fixtures preparation • • • Orders ------------------ Rev and recommendat 9 KI: view Project Progress: 04 • • ®_� � 4 fit -- Ix 41 fY � 1 • 41 r lt3��iJdr Tr,ya[ a1. �. ii` �y Y kl�y��rGLry�yp.aii o�GYJ�F t P�r'i F S,.YJ, 4 �L f f 't G'`��F.. •t�`l1MM r 4 J 1 f \l 4 Y r { ? iF el „ r �� I 1b .3aF���S//riVhh��Ai r 'Y�qgrM1ppyy� 1y�M1'�t�. J.m `t'uflky i`�.r, . .. .. .r 11 w • SL t1 1 • Y � t 3 v �4 \ 3 '. r !�i S' ♦�w p. , � ti Y.W. r e� A hhh { N al �eSa1, Att \. . ...� .c>• ._. 'y .[!, r v r �A� ¢ tY +•w A A } r tF q n I 1 "! RESOLUTION NO. 159-94 :• , ,„y�+�,tsa,�: �, ; f= A RESOLUTION OF THE CITY OF DANIA, FLORIDA, APPROVING PROPOSAL SUBMITTED AND JEFFERY GROSS/ASSOCIATES/ .i ARCHITECTS, P.A., RELATING TO CONSTRUCTION OF A NEW °t• CONFERENCE ROOM AT DANIA CITY HALL; AND PROVIDING FOR AN EFFECTIVE DATE. "F BE IT RESOLVED BY THE CITY COMMISSION OF THE CITY OF DANIA, + FLORIDA: t +It•s { lion 1 That the Proposal submitted by Jeffery Gross/Associates/Architects, P.A., relating to construction of a new conference room at Dania City Hall br , a copy of which is attached hereto as Exhibit "A", be and the same is hereby approved. �! " Section 2. That all resolutions parts of resolutions in conflict herewith be andkyPS Ix Y ons or VK <tt� r � 'J • the same are hereby repealed to the extent of such conflict. ` d r, Section 3 That this resolution shall be in force and take effect immediately upon ` its passage and adoption. 4 + �1't 3tr r„ • PASSED and ADOPTED on this 22 day of November , 1994. µ M� I Ft yb } jA1�Y til k ATTEST: Mayor- C missioner x a wT` fMy� Sf�,i lad' {r City Clerk -Auditor APPROVED AS TO FORM & CORRECTNESS Frank C. Adler, City Attorney "rux'r J'dr 1r.e+� k 159-94 Resolution No. �_ Y i ,t h3�i rr `IYN s � t ,�.—')1rt it �`Y _., ^ •i + A �t�is "`, *'Y+++,>».-+._..-.-, t ..-,i y< kr .d'•�i^r 4 ' �Y. � . ` d. v4 n q.. S, -1i F x I f j,�,4�'4✓ F, ^v >k' F t 1 rti�Gl I`I, iV 13..(Ci JEF ERY GROSS / ASSOCIATES / ARCHITECTS PA x, fir \ 18 November 199� ',,A I Mr. Will Allen Growth Management Director H City of Dania 100 Dania Beach Boulevard 't Dania FL 33004t `mow sa Re: Proposed new conference room at Dania City Hall `S`' ' ' yi Dear Mr. Allen: ,�' It is a pleasure to present this proposal to you. At this time the City of ,ksr Dania is proposing to construct a new conference room, at the existing City frY M . . Hall Structure. The space consists of approximately 1,400 square feet and r x the layout will be based on our previously completed space study. r>r My Firm would be pleased to provide the necessary services for your City. The project would be performed in three phases which would be as follows: k r • r Construction Documents-This phase of the work would cover the .i preparation of the project manual necessary for the preparation of bids by General Contractors and the Construction of the Project. { tiN cY Bidding-This phase of the work would include submission of the rtw�r�t Construction Documents to Generic Contractors for project bids and s . review of those bids with the Owner. Construction Administration-This phase of the work would include x field visits to tha Site and review of Construction. All services would be provided in accordance with our standard General Conditions. Fee's for the services listed above would be as follows: > xaw k Construction Document phase services would be performed for a lump sum amount of $6580.00. ' Bidding or negotiation and construction phase services would be ,'Fyi'+.$ based on an hourly rate. 1816 Sherman St. idaAA33020 305-925-3964 III. r, ���0�60• r xhn11�+11P J.} �M'• err ys r "i e . .. _ ,.�k;e",7'�^�•-r^�",3�dye" , I. ,. r xA.3N °����:sT7.. �.. .'� r..:rz.. r ..�. �� a t � >�t )xis-'�'E�` '• ���Js rAl Y 5 — y��� r<f • t 1'}t~ �y, ', •, r➢ -'i�lt" 'jdY II�AN t, A411�•t•7 tV` t5 a tti nr rya I 44 1A >1. _ P K* {ems J `�Sy�J�J11'N5 yy ;. An wL ��rr y�'4,A�r ry Sy cx 57 rL�? 4F��15d r!.'. kf V 1 �� � A5 tx•§� �'� �A 517r So4At lx Y II •yd r t i x. - }11 -;r Idnk4estimate of hours required for this project Our Hourly rates for any Owner services Would be Seventy Dollars per hour for the Principal, Drafting and Design Support Staff personnel. A retainer of 010 •• would be required prior to the start of th work with the r tiF balance work is completed, Looking forward to working with you •. Jef Jeff y Gross/Associates/Architects PA A A ulr'SX-f � •tq#wY FnN r� ;g� �Y ✓al iX��. —' fit. > d' tY�Z 'ij l�y a` 94021PR.DOC `# t kvt xC F- r.' 3 Y n y{rdba > ��Y�j�f'�rt by➢rF�� �� ����R Y� - ) r K F 4 Iti.,X r . y�{q}},u Y I I yi�f far I �FirY ��� t. I 4t�6 j S 1r tt 111C - 1 I 5 .ff 't47 le9�,uphy (F4'%k li 'rT .' '1 9 u^l t•.4 '. SI t� C i1 ( r A' r 7r/ / F5 r lY {� I ,J a r"P'`efi� fr t M 'S•� M+ �>V� �� ,1 ix.n�,fV�ra#� aaPi1�F,F...aaS.��r •. ( Ydn} f � NN �,1 c4 f f £t• 1 y 1 w r t f Yny T'f CITY OF DANIA 4� tr �^4 CONFERENCE ROOM �. SCHEDULE OF SERVICES ESTIMATED HOURS ERVI E , H r� Totals Y j %�M� � } 1,2 CONSTRUCTION DO UME IT PHAS E �� jc� Y7,e. .rb�kw�.i4; .Y� r�r ff <y�1l 1.2.1 Development of Architectural Construction Drawings (Construction Drawings will be on 24"x36" sheets) 1 1 A ryyf \ 01 Site L . ocation Plan No Scale 4 X.'`'Si` 02 First Floor Plan 7 1/4' = 1 '-0" y' .03 Roof Plan 8 05 Wall Sections 4 'J'ItibJ MJI 3/4" 12 06 Building Elevations 1/4 .08 Door Schedule Hardware Schedule & Details 8 �, .09 Finish Schedule & Details 4 �a 10 Specifications 4 teo-' rvt 10 ' � ? 1.2.2 Development of Structural Construction Documents 18 r .01 Foundation Plan 1/4"- 1'-On 4141 ` "`�;fi� 02 Roof Framing Plan 1/4 1 -0 03 Footing ' rxr' g, Column & Beam Schedules 1/4" .04 Details & Specifications w� 1.2.3 Development of Mechanical Construction Documents Y 15 ,. an First Floor Pl 1/4" = 1 '-0^ Schedule & Detail 1 n s 1/4"= 1 -0 Iryasu 'a 1.2.5 Development of Electrical Construction Documents 15 .01 First Floor Plan 02 Luminaire and Panel Schedules, Schematic i�. ul fir: r"!'I , +>� tr Diagram and Electrical Calculations r ' 1Z yp 1.3 BIDDIN slit r1 R1t OR NEG0TIeTION PHASE {3 .01 Preparation and distribution of Bidding ' fr.^r' Documents 3 Responses and explanation to 3 Bidders t over a two week bidding period. 12 .03 Receipt of requested Bids 1 � .04 Analysis and recommendation of Bids a° .05 Assistance in preparation of Construction 3 x sip,. s.� I t C ! JT f SSS' : !r v rryt i . 7' At yi tro7t{ ���r d I i.,, tr✓�i a,{ Contract .try ryr v.h.,' Drys! �p1 L.4 GONSTR �cTION PHASE ! 01 Processing of Shop Drawings and/or Submittals (5) t 7 15 i5y t Rebar, concrete tests, barjoist, a/c unit, electrical fixtures \ s 02 Review and preparation of Chan a Orders g 9 .03 Review and recommendation of Certificate for payment 12 .04 Site visits to review project progress 36 Final inspection to verify completion of work ! f TA 94021C2.DOC I 1 � � "^�sfrxylf..�/r5 3�'ti t � JbZSYy�a���fp y.144 y'' j l�. r LitA 15 ! , \ � i r < b.nj 3M Z3➢� pl %o r , r Y v�4]r1 Ili; i x� IF IF ?ILI f dj F. 5f I i . I� t:t 0 J ' I 4n tt l �L I f h , IMF r r � These images were produced in the normal course of business The Microfilm Depot/Advanced Imaging Solutions + 1213 South 30 Avenue, Hollywood, FL. 33020 ' Brow: (305) 927-4404 Dade: (305) 625-0509 4 • 471 hLt . i \ j 41 dl .1 R I y r i by"4.1:i }f� s �lj AIN- bot^'z� � v. 1 • . L \ ry ! Y n „ ti d�r�6txYk� , P1 Y',I �vra L'N ry'•• N y tx .f� raj ry yY L •�}, avyl Y' r�{, L ��I � y 'l�� A15n� f � © : . � . .a > : w. � , . . , � a � ^ � � ^ � � � © : � } � \ � � : . � � �f , �} � � 24 � � � �} �) . �) '} } � \ \ ��} \ � � \ �\ � � \ : . � � \ \ : . � � . �§ � \ \ \\ � � � | /\��� � � ` yy© « . &����? - . f » ,�%������d2 . � � � ���% w . . .