Loading...
HomeMy WebLinkAboutR-2023-085 Canseco Electrical Contractors Inc. Change Order for Directional Boring and Electrical Utility Installation ProjectRESOLUTION NO. 2023- A RESOLUTION OF THE CITY COMMISSION OF THE CITY OF DANIA BEACH, FLORIDA, AUTHORIZING THE PROPER CITY OFFICIALS TO APPROVE A CHANGE ORDER FOR THE DIRECTIONAL BORING AND ELECTRICAL UTILITY INSTALLATION PROJECT IN AN AMOUNT NOT TO EXCEED NINETY THREE THOUSAND EIGHT HUNDRED THIRTY SIX DOLLARS AND SIXTY ONE CENTS ($93,836.61); PROVIDING FOR SEVERABILITY; PROVIDING FOR CONFLICTS; FURTHER, PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, The City has an agreement with Canseco Electrical Contractors Inc. who are currently engaged in directional boring and electrical utility installation along certain medians within the City; and WHEREAS, the City's continuing efforts to enhance citywide aesthetics includes the installation of lit holiday decorations throughout its main corridors; and WHEREAS, the enhanced holiday decorations will require that electricity be provided to medians within busy thoroughfares; and WHEREAS, the project under way to accomplish this is complex and involves a method called underground directional boring to avoid the disruption of traffic and costly post -trenching roadway pavement restoration; and WHEREAS, in one segment of the project the directional boring has work has run into underground utilities that are often in the way of the conduit path, requiring that alternative measures be taken, which adds to the project cost; and WHEREAS, in addition to the directional boring issue, the project also needs to install temporary electrical meters to avoid delays in the final connection installations that are required prior to the coming holiday season; and WHEREAS, addressing these two situations requires a change order in the amount of Ninety Three Thousand Eight Hundred and Thirty Six Dollars and Sixty One Cents ($93,836.61). NOW, THEREFORE, BE IT ORDAINED BY THE CITY COMMISSION OF THE CITY OF DANIA BEACH, FLORIDA: Section 1. That the proper City officials are authorized to approve this change order in the amount of $93,836.61 to be funded from Infrastructure Improvements other than Buildings Account No. 301-39-60-541-63-10. Section 2. That if any section, clause, sentence, or phrase of this Resolution is for any reason held invalid or unconstitutional by a court of competent jurisdiction, the holding shall not affect the validity of the remaining portions of this Resolution. Section 3. That all resolutions or parts of resolutions in conflict with this Resolution are repealed to the extent of such conflict. Section 4. That this Resolution shall be effective 10 days after passage. PASSED AND ADOPTED on August 22, 2023. Motion by G: kmtr,t 45,(-'tC ¢', second by <-+Z, tki-1. FINAL VOTE ON ADOPTION: Commissioner Joyce Davis ` S Commissioner Tamara James f Commissioner Marco Salvino Vice Mayor Lori Lewellen \Alc Mayor Archibald J. Ryan IV ATTEST;:` �� o£ ELORA ROE , MMC _ to ARdlIBALb . RYANIV CITY CLERK �qpR°P MAYOR F 6 APPROVED AS TO FORM AND C( (- xs',' li / A. BOUTSIS CITY ATTORNEY RESOLUTION #2023- C✓L August 01, 2023 CEC' CANSECO GEMM3e e STATE CERTIFIED EC #13001295 2385 NW 70"' AVE-UNIN A03 Miami, FL 33122 1 P:(305)265-9909 I F:1305)265-9945. General Change Order #02 Cover Page City of Dania Beach, Florida Project: ITB No, 22-030 "Directional Boring and Electrical Utility Installation". Exhibit D, E, H, I. EOR: CGA - Calvin, Giordano & Associates, Inc. I800 Eller Drive, Suite 600 Fort Lauderdale, Florida 33316 Attn: Ms. Heidi Henderson & Mr. Jorge Cervantes Canseco Electrical Contractors is requesting a Change Order in the amount of $93,836.61 for the following changes from the original agreement: Exhibits H discovery of multiple underground utilities at different depths and location hinders the use of directional bore method with the potential of catastrophic damages to the critical underground utilities. Contractor performed good faith various location ground penetrating radar around the road crossing for location Exhibit H, the issue was discovered, and contractor immediately notified the engineers of record and suggested a potential solution contingent on approval of open -trench method, discussed with engineers to achieve the minimum FDOT acceptable coverage of 36" on top of the electrical conduit for electrical power inside median via road crossing. 2. Bid document specified Manufacturer " Millbank" current estimated build schedule is on back -order for the approved specified custom electrical meter/panel combos ordered for this project as per plan. After multiple dialogue with the manufacturer representative and engineer of record, a plausible solution was considered with FOR for alternative temporary solution to provide electrical power at each of the Four (4) Exhibits by furnishing and installing new alternate temporary standard electrical meter/panel combo gear, currently available at this time. Very truly, Canseco Electrical Contractors, Inc. (CEC Project #2210 — Document control) August 01, 2023 SEC CSC STATE CERTIFIED EC # 13001295 2385 NW 701" AVE - UNIT# A03 Miaml. FL 33122 1 P:(305)265-9909 16(305)265-9945 General Change Order #02 Cover Page City of Dania Beach, Florida Project: ITB No. 22-030 "Directional Boring and Electrical Utility Installation". Exhibit D, E, H, I. EOR: CGA - Calvin, Giordano & Associates, Inc. 1800 Eller Drive, Suite 600 Fort Lauderdale, Florida 33316 Attn: Ms. Heidi Henderson & Mr. Jorge Cervantes Canseco Electrical Contractors is requesting a Change Order in the total amount of $93,836.61 for the following changes from the original agreement: I. Temporary meters, while the original Milbank meters are in route. Proposed cost amount $17,930.61 2. Open trench method to achieve minimum FDOT acceptable coverage of 36" on top of electrical conduit. Pavement restoration at location H in lieu of bore due to conflict with existing utilities. Proposed cost amount $ 60,906.00 3. Contingency for unforeseen costs to complete the project. Proposed cost amount $15,000.00 Total sum amount for proposed change order #2: $ 93,836.61. Very truly, Canseco Electrical Contractors, Inc. (CEC Project #2210 — Document Control) Revision M �,�31A1QhiitalcAC9m STATE CERTIFIED EC 913001295 2385 NW 7011' AVE - UNIT# A03 Miami, FL 33122 P:(305)265-9909 ) F:1305)265-9945 www.cansecoelectric.com CHANGE ORDER REQUEST # 002 To: CGA - Calvin, Giordano & Associates, Inc. 1800 Eller Drive, Suite. 600 Fort Lauderdale, Florida 33316 Project: City of Dania Beach- ITB No. 22-030 "DIRECTIONAL BORING AND ELECTRICAL UTILITY INSTALLATION". Plan Exhibit D, E, H, I. Address: Griffin rd. ( East 195, West 195, SW32Ave, SW42Terr). Attn: Ms, Heidi Henderson I Mr, Jorge Cervantes CEC Project #+ 2210 Email: hhenderson(a)cgasolutions.wm I lcervantes@cgasoludons.com #1-Unforeseen multiple underground utility conflicts at Exhibit H road crossing - Multiple underground utility at different depths and location hinder the use of Directional bore method due to potential damage of said utilities, after GPR was performed at this location, this issue was discovered, proposed solution (contingent on approval is open -trench SUBJECT: method) discussed. with engineer to achieve the minimum FOOT acceptable coverage of aft. Discussed with FOR CGA. #2-Bid document specified Manufacturer " Millbank" currently is estimated build schedule is on back -order for the approved specified custom electrical meter combo panel on order for this project. a plausible solution was discussed with FOR for alternative temporary solution to, provide electrical power at each of the Four(4) Exhibits, furnish and Install new Temporary electric mete/combo panel. Detailed description of Changet INCLUDES: • Refer to breakdown for description of work attached. EXCLUDES: • Any work outside the detailed change order breakdown attached • Original Contract Scope of work • Bond Fees, Additional Insurance, other unforeseen conditions • FPL Hand -hole - FPL Fees I ANY Utilities Fees CHANGE ORDER CLARIFICATIONS. TERMS AND CONDITIONS: This change may Impact the critical path of the project schedule. This proposal does not Include moneys that affect, extended overhead, acceleration and/or Impact cost Canseco Electrical Contractors„ reserves its right to request additional compensation for general conditions, Impact costs and time extension which may result from this change, Impact cost may general conditions, impact costs and time extension which may result from this change. Impact cost may Include,, but are not limited to, compensation for time extension, extended overhead, loss of labor efficiency escalated costs, subcontractor claims and additional general condition moneys spent as a result of adding this work to our contract. These damages are not discernible at this time and are not Included in this proposal. However, when and if they become apparent we will advise and submit accordingly. Due to Market conditions, Items set forth on this quotation are subject to price Increases through time. Equipment lead subject to change without notice, This change order proposal is valid until for TEN (10) calendar days from date of proposal Date: August I, 2023 Page: 2 of 4 Revision #: 0 STATE CERTIFIED EC #13001295 CHANGE ORDER REQUEST# 002 Detailed description of Credit ® The total Applicable credits for all labor, material, tools and equipment previously estimated Is $ 5,228.62 • ® No applicable credits. Detailed description of Time Extension ® The above -described work will affect the Critical Path of the schedule requiring a time extension of 90 calendar days. This will impact to the critical path at an additional time. ® Will not affect the Critical Path of the schedule ® Canseco Electrical Contractors, Inc, respectfully reserve the right to request additional time based on additional work, material production, COVID-19 Impacts or unforeseen impact to the schedule. Total of Change Order Contractor Breakdown Subtotal: $ 86,825.67 Credit: $ 5,228.62 Subtotal less Credit: $ 81,597.05 15% Contractor Overhead & Profit: $ 12,239.56 Subtotal after Overhead & Profit: $ 93,836.61 TOTAL: $ 93,836.61 The total amount of _ Deducts / N/Adds Ichange order including overhead and profit less applicable credits is $ - 93,836.61 • Authorize person signature shall be responsible to pay in full "total amount" shown above. Initial Authorize person . Print Name Authorize person • Signature Title Date Detailed description of change order (if applicable) DlncerAkin Ozaydin, P.E epuly Public Sa vloes Director/City Enp CEC C,ANSEC O STATE CERTIFIED EC g13001295 2365 NW 700' AVE - UNITS A03 Miaml. FL 33122 ( P:(305)265-9909 I F:(305)265-9945 www.cansecoelectrlc.com Date: August 1, 2023 Prop City of Dania Beach. ITB No. 22-030 ^DIRECTIONAL BORING AND ELECTRICAL UTILITY INSTALLATION'. Plan Page: 3 o14 Exhibit D. E, H,1. Revlstonfk 0 Add: Griffin rd. ( fast 195. West 195. SW32Ave, SW42Terr) SUN #I -Unforeseen multiple underground utility conflicts at Exhibit H mad crossing+Multiple underground utility at different depths and location hinder the use of Directional bore method due to potential damage of said utilities. after GEE was performed at this location, this Issue was discovered, proposed solution (contingent on approval Is open -trench method) discussed with engineer to achieve the minimum FOOT acceptable coverage of aft. Discussed with FOR CGA. #2-Bid document specified Manufacturer Mlllbank" currently Is estimated build schedule is on back -order for the approved specified custom alectricat meter combo panel on order for this project. a plausible solution was discussed with FOR for alternative temporary solution m provide electrical power at each or the Four(4) Exhibits. furnish and install new Temporary electric metelcombo panel. NOTE; Msmrld Pdse subject re sIao, n per market mndl0om MaterW cost below wmprt to RSMeam Heaelal ehmge Order Cost Dam 2021, 33rd Edwon, or from RSMeans. BREAKDOWN FOR CHANGE ORDER# 002 lam MATERIAL QUANTITY UNIT MAT.PRICE Total Mat LUNIT Total Labor I Fora labor for routing hrom white line for unity. I LS $ S 5.00 Sp0 Exhibit H ( GrROn RD IF W of 195) 2 Erhnusd hand hbor op en ean.h digmg(do. to unknown u01' .IdewalUmedim) IS IF $ S 0.16 2-90 3 n-Altemadve MelerlPenel Combo - - - - 4 DectrlW rsuadd lot Me,- BOM(amch supplier quoin) 4 EA $ 909.31 $ 3.638.84 5.98 23,92 5 Sq. DSurg.Lo81c"' Type I Surge Proteabe Devices, 2006A 14DkA Per ph.. 4 EA $ 99.30 $ 392.20 D.3S0 IAD 6 30 Amp 9-Day 2x5PST 243Pcuft Astmnotelc Time Swlo9 4 EA $ 293.42 S I,173.80 0.99 3.96 2 Fhotoconuol- WaWlnundnamt Stain and 5 wd Rome.to Phoeo-o I, ,Gray 4 EA $ 20.98 $ 0.92 0.12 0.48 8 DeOMte Purpose Conactot CampattT eDPA 44'e1e, 30A 1101130Y CoD 4 EA $ 131.39 $ 525.56 1.262 5.05 9 unction Boa.Ng4A 4, Hinged. Soild Cover. 14x12xelnsL PoFyesmr/Guy 4 EA $ 21100 S 84E00 0.68D 2.72 10 Emnomisnew free -rend electrical rapport rack two post with Worse report pin.uni cast 4 FA $ 200.99 $ 3.155.76 4.26 IL03 11 Mbrulaneousmamrhl&hardwo.&support. I LS $ 3198 S 3198 0.90 0.90 SUB -TOTAL MATERIAL 9,956.34 LABOR 63.16 MATERIALS QTYI UNIT PRICE TOTAL MATERIAL MATERIALS 9.06.34 LS S 9.96.34 T. $ 689.94 TOTALMATERIAL COST If 10,54838 LABOR HIM RATED TOTALLABOR EleMchn(s) 63.2 51.49 $ 31251.48 SRe S, ummndmdforee. 11.2 8233 S 926.53 Prolact meager 9.0 10141 i 930.66 tabor burden 43% $ 2196.73 TOTALLARORCOST 6 1,305.39> Equipment Rent nqulpman, Taub, or servlce(s) QTY uPirr.oir TOTALSERVICE(S) Vendor Quote Ached- Open Trench Method 1 tS $ 41.660,00 R 41.660.00 Addidond 5114.0 restoration -per TOO r. requbs.vom(open venih) 1 IS $ 3.400.00 $ 3.450.00 Eehlbt H-Road dosure 4 EA g 1,208,50 $ 4,034.00 Open oauh explorers, con0lydnq 1 IS $ IS.M.0 s 15.000.0D S TOTAL SERVICE(S) COST IF 69,974.00 SIGN: DATE: r/JOB Rio 20R 12210-Chmge Orders Sub -Total Amountsr 1 6 06,025.61 Note Refer to cover pages for toms amount Ej '1. A V SEC EMEMM 2385 NW 70- AVE - UI•IITN AM Mi ml, FL 33122 I P:13051265-9909 I F.1:305)265-9945 www.canseCDelectri0.com Date: August 1, 2021 Prof. City of Dania Beach -ITS No, 22-030"DIRECTIONAL BORING AND ELECTRICAL UTILITY INSTALLATION". PI page: 4ef4 Add: Griinrd.(East 195.Wes095, SW32Ave, SW42Terr) Itevld.sAb 0 Sul #I -Unforeseen muidpie underground utility conflicts at Exhibit N road crossing - Multiple underground utility at different depths and location hinder the use of Dire<dona( bore method due to potential damage of said utilities. after GPR was performed at this location, this Issue was discovered, proposed solution (contingent on approval is open -trench method) discussed with engineer to achieve the minimum FOOT acceptable coverage of 3R. Discussed with FOR CGA. #2-Bid document specified Manufacturer "Mlilbank" currently is estimated build schedule Is on back -order for the approved specified custom electrical meter combo panel on order for this project, aplausible solution was discussed with FOR for alternative temporary solution to provide electrical power at each of the Four(4) EahiblD. furnish and Install new Temporary electric metefcombo panel, CREDIT BREAK -DOWN FOR CHANGE ORDER # 002 Item MATERIAL -(BID TIME COST) QUANTITY UNIT MAT.PRICE Total Met 1-UNIT Totallabor ExhibitHIGdHNRD& Wen Ni95) I use rvdk Reatorsoon 16 6Y $ 30.99 S 623.94 0.93 14.89 2 NI awardfu) 2 EA $ 143.89 $ 327.70 110 19 3 4 S 6 SUB -TOTAL MATERIAL 951.62 LABOR 17.3 MATERIALS (DID TIME COST) QTY.. if UNIT PRICE TOTAL MATERIAL MATERIALS 951.62 US $ 951.62 T. S 61.86 TOTAL MATERIAL COST 3 1,013.48 LABOR (BID TIME RATES FOR LABOR AND LARGE BURDEN) H/H RATED TOTAL LABOR BecVRlan 173 51.48 $ 090.2S She SuperinrandmdFo,.mm 3S B273 $ 204BI Labor burden 43% $ 471.74 TOTAL LABOR COST $ 1,566,60 Equfpmen4 Rentequipmen4 Tools, Pr 6ervlce(s) QTY UNITCOST TOTALSERVICE(S) 11 Uh1NtH(GdAIn RD& WEST0195)-. Dlnctional bore credit-Stroot CtosdnS 1 62 1 LF is 42.68 $ 2,6405 TOTAL SERVICE(S) COST I $ 2,E46.25 SIGN: DATE oc 1108 No 202112210-Change Orden credit Sub -Total Armando f 5,33B.63 Note Refer to cover pages to, umlamaunt Ramon I Canseco From: Heidi Henderson <HHenderson@cgasolutions.com> Sent: Thursday, July 20, 2023 2:19 PM To: Ramon J. Canseco Cc: Jorge Cervantes; Ramon Canseco; Canseco Electrical Contractors; Ozaydin, Dincer A. Subject: RE: Holiday Lights Phase 3 - Exhibit H - Conflict - Open trench Method - CO #02 Attachments: 1-CO #002 - Open trench method (Exhibit H)_07,05,2023.pdf Hi Ramon, 1. Please confirm that the required 30-inch cover is able to be met over the conduit. 2. Please confirm what utility that the conduit will cross 3. Please confirm the separation from the utility(ies) it crosses. If you could please provide a cross section per our conversation, that would be great. Also, please provide the costs for the temporary meters as soon as you can. We need to get those approved and installed at the other 3-locations-as soon as possible to close out the permit in time. Please confirm that we can have the as-builts by the end of July as planned. The city called me again today and continued to relay the importance of this project and how it must be completed on time. Once I have the information above, I can better discuss the CO request with the city. Please advise. Thank you so much. Heidi Belle Henderson, P.E. Project Manager x Calvin, Giordano & Associates, Inc. - a.SAFEbuilt Company 1800 Eller Drive I Suite 600 ( Fort Lauderdale, FL 33316 Office: 954.921.77811 Direct:954.266,6484 1 Fax:954.921,8807 Cell: 305.450.2971 Fort Lauderdale ( Mlamf-Dade I West Palm Beach / Cleorwater/rampo I Estero I Port St. Lurie From: Ramon J, Canseco <ramonjr@cansecoelectrlc.com> Sent: Wednesday, July 19, 2023 1:00 PM To: Heidi Henderson <HHenderson@cgasolutions,com> Cc: Jorge Cervantes <jervantes@cgasolutions.com>; Ramon Canseco <rc@cansecoelectric.com>; Canseco Electrical Contractors <cec@cansecoelectric.com> Subject: RE: Holiday Lights Phase 3 - Exhibit H - Conflict - Open trench Method - CO #02 Dear Heidi, Ramon J. Canseco From: Ramon J. Canseco Sent: Thursday, July 20, 2023 4:05 PM To: Heidi Henderson Cc: Jorge Cervantes; Ramon Canseco; Canseco Electrical Contractors; Ozaydin, Dincer A. Subject: RE: Holiday Lights Phase 3 - Exhibit H - Conflict - Open trench Method - CO #02 Heidi, I spoke with open trench vendor, per his quote "all repair necessary to comply with FDOT standards", meaning railroad and 50ft one way. If an additional 5011 the other way is needed, he said we should add roughly 7K to his quote. Regarding the directional bore, Adrian previously mentioned he could shoot a depth between 24" -29" below A.F.F. to avoid the utilities. I have just sent an email request to Adrian to clarify. From my recollection of the underground utility conflict for road crossing were: TECO, Water, Power, Telecom, and one more. The separation, I do not have this information. I know telecom is running below sidewalk/curb. I'm working on the temp meters and as-builts. Thank you. Sincerely, Ramon J. Canseco CANSECO ELECTRICAL CONTRACTORS, INC. Email: ramonirOcansecoelectrlc.com Off: (305) 265-9909 Cell: (786) 255.4718 Fax: (305) 265-9945 CONFIDENTIALITY WARNING: This email may contain confidential or proprietary business information and is for the sole use of the intended recipient(s). Any unauthorized use or disclosure of this communication, including attachments, Is strictly prohibited. If you believe that you have received this email in error, please notify the sender immediately and delete. From: Heidi Henderson <HHenderson@cgasolutions.com> Sent: Thursday, July 20, 2023 2:27 PM To: Ramon J. Canseco <ramonjr@cansecoelectric.com> Cc: Jorge Cervantes <jcervantes@cgasolutions.com>; Ramon Canseco <rc@cansecoelectric.com>; Canseco Electrical Contractors <cec@cansecoelectric.com>; Ozaydin, Dincer A. <dozaydin@danlabeachfl.gov> Subject: RE: Holiday Lights Phase 3 - Exhibit H - Conflict - Open trench Method - CO #02 Hi Ramon, Pleasetconfirm this is for the 50-feet restoration In both ways or is It to the railroad to the west and 50-feet to the east perFDB;Teq'u.....is,'_________ ______®__. Please provide a markup of the pavement restoration area proposed. Thank you so much. Heidi Belle Henderson, P.E. Project Manager x Calvin, Giordano & Associates, Inc. - a SAFEbuilt Company 1800 Eller Drive I Suite 600 1 Fort Lauderdale, FL 33316 Office: 954.921.77811 Direct: 954.266.6484 ( Fax: 954,921.8807 Cell: 305.450.2971 Fort Lauderdale / Miami -Dade /West Palm Beach / Clearwater/Tampa / Estero / Port St Lucie From: Heidi Henderson Sent: Thursday, July 20, 2023 2:19 PM To: Ramon J, Canseco <ramonjr@cansecoelectric.com> Cc: Jorge Cervantes <jervantes@cgasolutions.com>; Ramon Canseco <rc@cansecoelectric.com>; Canseco Electrical Contractors <cec@cansecoelectric.com>; Ozaydin, Dincer A. <dozaydin@daniabeachfl.gov> Subject: RE: Holiday Lights Phase 3 - Exhibit H - Conflict- Open trench Method - CO #02 H1 Ramon, 1. Please confirm that the required 30-inch cover is able to be met over the conduit. 2. Please confirm what utility that the conduit will cross 3. Please confirm the separation from the utility(les) it crosses. If you could please provide a cross section per our conversation, that would be great, Also, please provide the costs for the temporary meters as soon as you can. We need to get those approved and installed at the other 3 locations as soon as possible to close out the permit in time. Please confirm that we can have the as-builts by the end of July as planned. The city called me again today and continued to relay the importance of this project and how it must be completed on time. Once I have the information above, I can better discuss the CO request with the city. Please advise. Thank you so much. Heidi Belle Henderson, P.E. Project Manager Calvin, Giordano & Associates, Inc. - a SAFEbuilt Company r 1800 Eller Drive I Suite 600 1 Fort Lauderdale, FL 33316 Office: 954.921.77811 Direct: 954.266.6484 1 Fax: 954.921,8807 Cell: 305,450.2971 Fort Lauderdale / Miami -Dade / West Palm Beach / ClearwaterlFampa / Estero / Port St. Lucie www.cansecoelectric.com VENDOR's QUOTE: OPEN TRENCH Dekora, L.L.C. Tel. No.: (786)573-1672 12011 SW 129THCT Unit#5 Fax: (305)397-2706 Miami, FL 33186 Email: dekoralic@gmaO.com Revised Quote Customer: CANSECO ELECTRICAL CONTRACTORS, INC. Date: 7/1912023 Project: City of Dania Beach PHONE: 305-265-9909 Holiday Lighting Project Attention: Ramon J. Canseco By: Javier Rodriguez Total Quantity Unit Item Description Unit Price Ext, 1 EA Lum sum: Dakota LLC proposes the following: 41 660.00 41 660.00 Scope of Work: Open trench.deRth of '-4" . full repair and restore of sidewalk traffic plate, fill/haul material, all repair necessary to comply with FDOT standards.Distance estimate: 601ft. to Include the hand excavation labor of 15-201f " Price to Includespecial required insurance to work within railroad tracks proximity SPECIAL QUOTATION (Comment or Instruction) These Prices are nood for 30 days from date of quote. TOTAL $ 41 66D.00 If you are satisfied with this quote, please sign below and return to our office. Exhibit H - Area of concern / Open Trench method 4UN-PH RLdwg - (Plotlatl by Jorge Carvontac on Fritlny, Aprll 14, 2023 41a:n PR) (Platted by: Katharine Kupsky on Thursday, August 11, 2022 1:52:25 PM) .o o� a �o 4 9 7 L N I H N1:UDD1 i° S2 (BONDED) (BONDED) SERVICE 4 GROUND " � LI 4. ♦ e�e +I b 42,734' h 12' �yy LANDING MIN. p ^d 7 63' m �^ u, S LW m 53.141' 1 �6 i ELECTRICAL SUPPLIES, INC, Our Peapla Gloka The Dilloonro. ELECTRICAL SUPPLIES INC, MIAMI 13395 NW 107TH AVE HIALEAH GARDENS, FL 33018 Phone 305-702-6001 QUOTE TO: CANSECO ELECTRICAL CONTRACTORS 2385 NW 70TH AVENUE UNIT A3 MIAMI, FL 33122 Quotation EXPIRATION DATE QUOTE NUMBER 07/20/2023 S101231192 PAGE NO. ELECTRICAL SUPPLIES INC, MIAMI 13395 NW 90TTH AVE HIALEAH GARDENS, FL 33019 Phone 305-702-6001 1 of 1 SHIP TO: CANSECO ELECTRICAL CONTRACTORS 2385 NW 70TH AVENUE UNIT A3 MIAMI, FL 33122 CUSTOMER NUMBER CUSTOMER PO NUMBER JOB NAME / RELEASE NUMBER. SALESPERSON 643 Frank Rivero WRITER SHIP VIA TERMS SHIP DATE FREIGHT ALLOWED Frank Rivero OT OUR TRUCK PASS -ALONG 06/20/2023 No ORDER QTY DESCRIPTION UNIT PRICE EXT PRICE 4ea QC816F150C 447.707/ea 1790.83 SQD QC816F150C METER MAIN RING 4ea LANUAT131XGF 105.378/ea 421.51 SIEM5 UAT131-XGF 135A 4J RGLST 4ea QO124L125PGRB 225.7831ea 903.13 SQD QO124L125PGRB QO PLUG -ON N 4ea QOM60VH 52,889/ea 211.56 SQD QOM60VH MINIATURE CIRCUIT 24ea Q0120 12.992/ea 311.81 SQD Q0120 MINIATURE CIRCUIT BR ** BID PRICING IN EFFECT 48 HRS FROM ORDER DATE *** Subtotal 3638.84 S&H Charges 0.00 Sales Tax 254.72 Amount Due 3893.56 Prated By: FRANK on 0120/20231:11A4 PM EDT CANSECO ELECTRICAL CONTR... 182573 Categories I, Boxes & Enclosures k Enclosures - Corrosion Resistant � PVC / Polyester Enclosures e PVC / Polyester Hinge Cover Enclosures =+ My Lists Q Add to Preferred A Share Made In USA NVENTHOFFMAN Junction Box, NEMA 4X, Hinged Cover,14" x 12" x 8" Item #: 33735 Cat #: A14128PHC UPC: 783510170776 ADD PART # Documents & Guides Cut Sheet Junction Box, NEMA 4X, Hinged, Solid Cover,14 x 12 x 8 Inch, Polyester/Gray View product detail below $212.00 EA Miami #1597: 0 in stock More Locations 0 Manufacturer Inventory: 350 Company wide: 17 Orlando - DC: 0 ----- --- ----- — -- ------ - - ADD TO CART Associated (7) Substitutes Others Bought (24) NVEN NVEN NVEN NVEN HOFF HOFF HOFF HOFF A14P' A14P' A1412 ATPG Panel Panel Panel Touci Item: Item: Item: Item: 3660• 359T $ 27625 p Quick View $ O Quick View $ U Quick View 63.4 O Quick View $ 84.; 32.: 28.11 EA EA EA EA -i- I ADD TO C�. + ADD TO CAI --i- I ADD TO C ADD TO CA l VIEW ALL Overview Junction Box, NEMA 4X, Hinged, Solid Cover,14 x 12 x 8 Inch, Polyester/Gray nVent HOFFMAN HOFA14128PHC PolyPro polyester enclosures perform exceptionally well in applications where harsh chemicals, weather extremes and corrosive environments demand toughness from a lightweight enclosure. Providing excellent ultraviolet protection and a tight environmental seal, these Ramon's Menu zo Cxi'aybaR. ® Product has been removed from your cart. Cart Delivery Method for Order Changing your delivery method may affect the availability of Items In your cart. Q Ship To 203204 1 CANSECO ELECTRCAL You CONTRACTOR 2385 NW 70TH AVE. UNIT AS MIAMI, FL 33122 Change ship -To U Pick Up at Branch FORT LAUDERDALE, FL 33312 * Ship my order as Complete Delivery What's,this7 ITEM UNIT PRICE MANUFACTURER: SQUARE D (SCHNEIDER $184,67/1 ea ELECTRIC) Surgel-ogl& Type 1 Surge Protective Devices, 2OOkA MFR#: SDSA3650 SKU: 93145021 Minimum order i each. MANUFACTURER: SQUARE D (SCHNEIDER $131.39 / 1 ea d ELECTRIC) Definite Purpose Contactor, Compact, Type DPA, 4-Pole, 30A, 110/120V Coil MFR#:8910DPA34VO2 SKU:90059588 Minimum order 1 each. R Total(2 $1,264.24 Items) CHECK OUT CONVERT TO RFQ * Cart Action CITY AVAILABILITY... Delete Cart TOTAL Add to Favorites 4 In Stock '., Export CS$738.68 ea Export PDF Remove 4 In Stock ea $525.56 Remove ORDER SUMMARY Subtotal:$1,264.24 Shipping: TED Square D (Schnelder Elec dc) Surgelogico Type 1 Surge Protective Devices, 200kA View Detalis ECCN EAR99 Country of Origin United States UNSPSC 39121101 Max. Surge Current 1304foules Protection Type Type I Surge Protection Amperage Rating 40kA per Phase Voltage Canfiguradon 1202401201208,2771480, AC,3-Phase, 4-Wire SKU MFRd 0 In Swckw Ship 93145021 SDSA3650 ® In Swckfor Pkk Up $184.67/EA x AVAIL1elLM ® In Stockto Ship (87 Available) 01n Stackta Pick Up (12 Available) 0 Available for Backorder QUANTITY::, 1 Items sold In each. Minimum order each. ADD TO FAVORITES Swck Dcwiis ,. STOCK LOCATION CIMSfATE QUANTITY Grayber South Flodda FORTLAUDERDAIE, FL 12 Service Center Graybar Tampa Service RIVERVIEW,FL 75 Center Nohncivandty lined here may notreletteli avaxabnar ppesandit abgay.a ronnrorm.npn.I ere only. I` - d �• i,l� suu. it o lsc +namn utamq Definite Purpose Contactor,Compact,nrpeDPA, 4-Pole,30A,fl0/120VCoil r ci SKU.M9100PA3aV02 S8U:9005958a *•; nt ® OeBnitepurpaserantador30A600V.9-poleontanorwkhttWt2Wmll voltage, opentype enclosure and quick connenterminals. vlawMore Product Details n ECM W99 UNSPSC 39121529 coumryororigin CN-China Ampera.. N.Vng 30A -- Coilvallage 110112ovat ®sp nu.,:nm,eat La u, In., 513139ru rt x mar . vl..a. AamNbx m 0 inftakta SMp(bt a in5la[h 1prNQUp(p orwanaelerareauamer =Sp0,naW1AOj ,ww9s,...�e uagndr>pr.,m.Ywi gab. Aooto ravoann 81 Home Improvement Retailer Your Cart (2) r-J Share Remove An (tams Checkout Pickup N Hollywood/Stirling (2 Items) Curbside Available 0 This Item Is only returnable in store. Intermatic NIGHTFOX 1,000-Watt LED/Incandescent Stem 1,13 " and Swivel Electronic Photocontrol, Gray Model#EK4236SD89 $20.98 Pickup at N Hollywood/Stirling Delivering to 33122 Delivery t Saturday, Jul 22 9l available FREE Save for Later Save to Favorites Remove 0 This item is only returnable In store Intermatic 30 Amp 7-Day SPST 1-Circuit Astronomic Time Switch Model #Er8015C $239.16 Pickup at N Hollywood/Stirling Delivering to 33122 F Store Delivery ul 31 Thursday, Jul 27 5 available FREE © Add a Home Depot Protection Plan by Allstate? 2-year Protection for $35.00 Learn More Save for Later Save to Favorites Remove Need Help? See our online FA09 or phone us: Online Customer Suppoda-800-430-3376 Major Appliances:"77-961-6683 Custom Bllnds:1-800-658-7320 CIA 7 days a week - 6 a.m. to 2 a.m. EST Subtotal. $260.14 Pickup FREE Sales Ta%(dete Tined in later step) --- Total $260t4 Have a promo code?